Artificial Intelligence
Builders Company
Developers/Aktor Group
AG
Aktor GroupPaiania, Greece · founded 1987
PUBLIC LISTED

Aktor Group develops and constructs large-scale infrastructure, transport, energy, renewable-energy, commercial real-estate and facility-management assets in Greece and selected international markets for public authorities, institutional partners, businesses and communities.

Years in business
39
founded 1987
LinkedIn headcount
1,549
employees, as shown on LinkedIn · size band 1,001–5,000
Total projects
~400
across the company’s whole history
Projects last researched October 10, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
AKTOR SOCIÉTÉ ANONYME HOLDING COMPANY TECHNICAL AND ENERGY PROJECTS1
Headquarters
19th km Paiania – Markopoulo Ave1, Paiania1, Greece
Founded
19871
Entity type
PUBLIC LISTED1
Business model
contracting3, commercial3, other2
Markets
not published
What they build
Hotel (2 of 4) · Office (1 of 4) · Retail (1 of 4)
Full dossier in About →

Delivery record

1 date-assessed of 4 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
4
within the rolling ten-year window
Median delay
−0.5 mo
the middle of 1 scored project
Average delay
−0.5 mo
the same projects, pulled by the worst
Average time to deliver
—
1 delivered project with a dated start — needs 3
Worst slip
−0.5 mo
Branco Mykonos · −6.0 to +5.0
1
early or less than 6 months late
6 to 12 months late
0
yellow rows below
Over 12 months late
0
red rows below

Against other developers

1 date-assessed project here
Not enough info yet.
Projects and timelines in Track Record →

Resident experience

2 of 4 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.7/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (2 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
7.7/ 10
Fabric, services, waterproofing, envelope · from 2 of 2 rated buildings
Management & living
7.8/ 10
Upkeep, response times, amenities, community · from 2 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in Greece yet to compare against.
Ratings by building →

Awards & recognition

  • PROJECT AWARD Winner 2024-10-07 (reported)
    Special Award — Construction Project of the Year 2023 · Riviera Tower, Elliniko
    The BOUYGUES–INTRAKAT joint venture was reported as receiving the special award for the Riviera Tower project, recognising more than 40 continuous hours of raft-foundation concrete pouring and a reported Greek record.
    Infrastructure & Transport Conference (ITC 2024) · https://www.linkedin.com/feed/update/urn:li:activity:7249115782347972608
  • COMPANY AWARD Winner 2023
    Protagonists of the Greek Economy 2023 — Development and Investment
    The developer reports receiving the 2023 award in the Development and Investment category, an institution described as recognising businesses supporting the Greek economy based on published financial data and market assessment.
  • PROJECT AWARD Winner 2021-07-01 (reported; award for 2019)
    Project of the Year 2019 · Thessaloniki Airport “Makedonia” upgrade
    Intrakat and Fraport Greece were named recipients of the Project of the Year 2019 award for the upgrade of Thessaloniki Airport “Makedonia,” presented by Greece’s Minister of Infrastructure and Transport.
  • 1 more in Awards
All awards →

Risks & source coverage

  • PROJECT CANCELLED 11 November 2024 (termination reported); project was reported as about 30% complete On 11 November 2024, Cyprus’s Public Works Department terminated Intrakat’s contract for Phase 1 of the Paphos–Polis Chrysochous highway, citing significant and unjustified contractor delays; the department said the contractor had completed about 30% and would be replaced through a new tender. Intrakat disputed responsibility, attributing the impasse to excavation, materials, disposal-site and government-response problems, and sought damages through the courts.
  • DELIVERY DELAY 4 March 2023 (status reported); original deadline 2016; fiscal correction validated 26 June 2019 A 2014 rail-signalling contract involving TOMI, an Ellaktor subsidiary, and Alstom—covering work attributed in reporting to the Aktor/Alstom consortium—missed its 2016 deadline, received successive extensions and had stalled; an audit validated in 2019 required recovery of €2.42 million from project manager ERGOSE for deficient studies and failure to provide required know-how, while a €13.3 million supplementary contract was signed in 2022 and the system was still not operational when reported in March 2023.
  • REGULATORY 10 March 2017 (decision published); conduct covered 2005–2012 In a final 10 March 2017 settlement decision, the Hellenic Competition Commission found that Intrakat and other contractors had accepted participation in a 2005–2012 public-works bid-rigging and market-allocation scheme and imposed a €4,300,493 fine on Intrakat; the decision records that the infringement finding was not appealed.
  • 1 more in Risk & Sources
Record status
active
Company sources
115 source entries across 110 fields
Projects tracked
4 · 4 completed in assessment
All flags and sources →

Track Record

Delivery record

1 date-assessed of 4 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
4
within the rolling ten-year window
Median delay
−0.5 mo
the middle of 1 scored project
Average delay
−0.5 mo
the same projects, pulled by the worst
Average time to deliver
—
1 delivered project with a dated start — needs 3
Worst slip
−0.5 mo
Branco Mykonos · −6.0 to +5.0
1
early or less than 6 months late
6 to 12 months late
0
yellow rows below
Over 12 months late
0
red rows below

Against other developers

1 date-assessed project here
Not enough info yet.

Construction start to handover

4 of 4 projects dated · 2 places
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
Athens, Greece
Mykonos, Greece
20172018201920202021202220232024202520262027todayATHENS, GREECEcompleted, no target publishedon timeestimatedMYKONOS, GREECEdates under review−0.5 moverified
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures.

Building & Livability Ratings

Resident experience

2 of 4 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.7/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (2 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
7.7/ 10
Fabric, services, waterproofing, envelope · from 2 of 2 rated buildings
Management & living
7.8/ 10
Upkeep, response times, amenities, community · from 2 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in Greece yet to compare against.

By building

2 rated · 2 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
Xenodocheio MilosΠαλιά Βουλή, Athens42 units
9.1/ 10
7.8/ 10
7.8/ 10
KAYAK 10/10, 9/10, 8/10, 7/10, 7/10 · 455 reviews · kayak.com
Tripadvisor 5/5, 5/5, 5/5, 4.6/5, 4.8/5 · 43 reviews · tripadvisor.com
Agoda 9.7/10, 9.6/10, 9.3/10, 8.6/10, 8.5/10 · 680 reviews · agoda.com
Combined from 15 published figures on 3 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.8.

KAYAK’s 9.3/10 from 455 verified guest reviews is the largest published review base and converts to 8.6/10 under the requested curve. Tripadvisor’s 4.9/5 and Agoda’s 9.4/10 are supportive but smaller or differently aggregated; the reported operational and physical caveats justify a modest net adjustment to 8.4 overall. Structure is separately held at 7.8 because the evidence is mainly room-condition and safety feedback rather than a full engineering assessment.

+ Comfortable rooms+ Good room condition+ Effective air-conditioning+ Mostly soundproof rooms+ Quality finishes
− Slippery marble− No shower nonslip mat− No staircase handrails noted− Some rooms not massive
Not found in sources: No published engineering detail
+ Warm staff+ Responsive concierge+ Excellent cleanliness+ Central walkability+ Strong restaurant and breakfast
− Breakfast ordering delays− Breakfast repetition/price concerns− Small lobby− Limited extra facilities− Potential central-city noise

Published guest feedback describes rooms as spacious, comfortable and in good condition, with one review specifically praising “great AC” and rooms that were “almost completely soundproofed.” The principal physical-safety criticism was that the marble was “extremely slick when wet,” with a request for handrails and nonslip shower mats; no detailed engineering, plumbing, HVAC or waterproofing report was published.

Daily-life feedback is strongly positive: reviewers describe staff as “warm, welcoming, and incredibly accommodating,” and Tripadvisor’s published service and cleanliness sub-scores are both 5.0/5. The recurring qualification is breakfast operations—one review says the service was “overrun” and did not answer the phone—while other published summaries mention repetition or expense; one guest also reported central-city noise.

Branco MykonosPlatis Gialos, Mykonos21 units
8.3/ 10
7.5/ 10
7.9/ 10
Agoda 9.8/10, 9.7/10, 9.3/10, 9.3/10, 8.7/10 · 343 reviews · agoda.com
Booking.com 9.7/10, 9.6/10, 9.6/10, 9.5/10, 9.1/10 · 242 reviews · booking.com
Trip.com 9.4/10, 9.4/10, 9.3/10 · 40 reviews · gr.trip.com
Tripadvisor 2.8/5 · 8 reviews · tripadvisor.com
Combined from 14 published figures on 4 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.9.

Google's 4.5/5 from 1,207 reviews is the largest review base and converts to 8.5 under the supplied curve, so it sets the level. The score is moderated by repeated noise and room/system complaints, while repeated praise for staff, beach access, breakfast and facilities provides a smaller offset; the evidence is from hotel guests and should not be read as a resident-tenancy record.

+ Well-kept rooms+ Clean rooms+ Comfortable beds+ Stylish design+ Beach/pool facilities
− Humidity marks− Shower repairs− Shower-pressure issues− Hot/cold water issues− Sink-drainage issues
+ Friendly staff+ Attentive service+ Beach access+ Strong breakfast+ Pool and beach amenities
− Loud DJ music− Party atmosphere− Early rubbish noise− High food and drink prices− Limited quiet

Published guest feedback is mostly positive about room cleanliness, comfort and design, but it also contains specific maintenance observations. One reviewer reported changing rooms because of “humidity marks and visible shower repairs,” while another described recurring-looking plumbing symptoms involving “shower pressure, hot / cold water and sink drainage”; these are guest reports rather than an engineering inspection.

Daily life is strongly praised for service, beach access, breakfast and facilities: guests describe staff as “super kind and friendly,” call the breakfast “one of the best,” and praise the beachfront setting. The main operational drawback is noise: one review says the DJ played “at an absurdly loud level from 11a-11:30p every single day,” while another says silence in the bedroom was not possible; the evidence is guest-based and reflects a hospitality property rather than a conventional residential building.

Only buildings that have reached handover are rated. 2 of 4 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
AKTOR SOCIÉTÉ ANONYME HOLDING COMPANY TECHNICAL AND ENERGY PROJECTS
Headquarters
19th km Paiania – Markopoulo Ave, Paiania, Greece
190 02
Founded
1987
Entity type
PUBLIC LISTED
Revenue
EUR 1.395 million
2025
Business model
contracting, commercial, other

Partners

4 partners
Bouygues Batiment International
contractor

Riviera Tower construction partnership

ELLINIKON S.A.
government partner

Commissioning of Riviera Tower

PPC Group
joint venture

Joint development of RES portfolio up to 2.7 GW

DEPA Commercial
joint venture

Atlantic-SEE LNG joint venture for LNG import and trading

Sources: name

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
...being developed in partnership with Bouygues Batiment International.
value seen: Bouygues Batiment International
Riviera Tower - Aktor Group

Sources: partner type

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
AKTOR Group is undertaking the iconic construction ... in partnership with Bouygues Batiment International.
value seen: CONTRACTOR
value paraphrased from this source
Riviera Tower - Aktor Group

Sources: summary

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
AKTOR Group is undertaking the iconic construction of the Riviera Tower ... in partnership with Bouygues Batiment International.
value seen: Riviera Tower construction partnership
held out of the figures · the quote does not carry this value
value paraphrased from this source
Riviera Tower - Aktor Group

Sources: name

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
This project, commissioned by ELLINIKON S.A.
value seen: ELLINIKON S.A.
Riviera Tower - Aktor Group

Sources: partner type

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
commissioned by ELLINIKON S.A.
value seen: GOVERNMENT_PARTNER
value paraphrased from this source
Riviera Tower - Aktor Group

Sources: summary

COMPANYdate not shown in source

https://aktor.gr/en/projects/riviera-tower/

Aktor Group
This project, commissioned by ELLINIKON S.A.
value seen: Commissioning of Riviera Tower
held out of the figures · the quote does not carry this value
value paraphrased from this source
Riviera Tower - Aktor Group

Sources: name

COMPANYdate not shown in source

https://aktor.gr/en/projects/ppc-strategic-partnership/

Aktor Group
The AKTOR Group and the PPC Group have entered into a Framework Cooperation Agreement for the joint development of a RES portfolio
value seen: PPC Group
PPC Strategic Partnership - Aktor Group

Sources: partner type

COMPANYdate not shown in source

https://aktor.gr/en/projects/ppc-strategic-partnership/

Aktor Group
Framework Cooperation Agreement for the joint development of a RES portfolio
value seen: JV_PARTNER
value paraphrased from this source
PPC Strategic Partnership - Aktor Group

Sources: summary

COMPANYdate not shown in source

https://aktor.gr/en/projects/ppc-strategic-partnership/

Aktor Group
The AKTOR Group and the PPC Group have entered into a Framework Cooperation Agreement for the joint development of a RES portfolio with a total capacity of up to 2.7 GW
value seen: Joint development of RES portfolio up to 2.7 GW
held out of the figures · the quote does not carry this value
PPC Strategic Partnership - Aktor Group

Sources: name

PRESSdate not shown in source

https://ventureglobal.com/2026/06/11/venture-global-and-atlantic-see-announce-expansion-of-long-term-lng-sales-and-purchase-agreement-with-greece/

Venture Global
ATLANTIC – SEE LNG TRADE is a company in which AKTOR Group of Companies holds a 60% stake and DEPA Commercial holds 40%
value seen: DEPA Commercial
Venture Global and Atlantic-SEE Announce Expansion of Long-Term LNG Sales and Purchase Agreement with Greece

Sources: partner type

PRESSdate not shown in source

https://ventureglobal.com/2026/06/11/venture-global-and-atlantic-see-announce-expansion-of-long-term-lng-sales-and-purchase-agreement-with-greece/

Venture Global
ATLANTIC – SEE LNG TRADE is a company in which AKTOR Group of Companies holds a 60% stake and DEPA Commercial holds 40%
value seen: JV_PARTNER
value paraphrased from this source
Venture Global and Atlantic-SEE Announce Expansion of Long-Term LNG Sales and Purchase Agreement with Greece

Sources: summary

PRESSdate not shown in source

https://ventureglobal.com/2026/06/11/venture-global-and-atlantic-see-announce-expansion-of-long-term-lng-sales-and-purchase-agreement-with-greece/

Venture Global
Its goal is to import Liquefied Natural Gas (LNG) into Greece and trade it across Eastern and Southeastern Europe
value seen: Atlantic-SEE LNG joint venture for LNG import and trading
held out of the figures · the quote does not carry this value
value paraphrased from this source
Venture Global and Atlantic-SEE Announce Expansion of Long-Term LNG Sales and Purchase Agreement with Greece

Registrations & licences

COMPANY NUMBER000408501000
General Commercial Registry (GEMI) · Greece
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

0 countries

What they build

4 types
Hotel2 of 4
Office1 of 4
Retail1 of 4
Other1 of 4
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
AE
Alexandros Exarchou
The group’s chairman and CEO, also leading ATLANTIC SEE LNG TRADE. Aktor describes more than 30 years in public-project construction across Greece, Europe, the Middle East and North Africa.
Current title
Chairman and CEO of AKTOR Group of Companies; CEO of ATLANTIC SEE LNG TRADE
since Jul 2022 - Present
Experience
no career length stated
Companies before
none sourced
Education
University of Thessaloniki Law Schoolbachelor’s degree
University of Manchester School of LawMaster of Law
Other boards
none sourced
Known for
nothing tagged
https://gr.linkedin.com/in/alexandros-exarchou-019571364

Sources: degree

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Exarchou holds a bachelor’s degree from the University of Thessaloniki Law School, a diploma in English Legal Studies and a Master of Law from the School of Law of University of Manchester.
value seen: bachelor’s degree
https://aktor.gr/en/leadership/

Sources: institution

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Exarchou holds a bachelor’s degree from the University of Thessaloniki Law School, a diploma in English Legal Studies and a Master of Law from the School of Law of University of Manchester.
value seen: University of Thessaloniki Law School
https://aktor.gr/en/leadership/

Sources: degree

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Exarchou holds a bachelor’s degree from the University of Thessaloniki Law School, a diploma in English Legal Studies and a Master of Law from the School of Law of University of Manchester.
value seen: Master of Law
https://aktor.gr/en/leadership/

Sources: institution

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Exarchou holds a bachelor’s degree from the University of Thessaloniki Law School, a diploma in English Legal Studies and a Master of Law from the School of Law of University of Manchester.
value seen: University of Manchester School of Law
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://aktor.gr/en/leadership/

Sources: full name

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Alexandros Exarchou is the Chairman and CEO of AKTOR Group of Companies, and CEO of ATLANTIC SEE LNG TRADE.
value seen: Alexandros Exarchou
https://aktor.gr/en/leadership/

Sources: linkedin page

SOCIALdate not shown in source

Alexandros Exarchou

LinkedIn
### Chairman and CEO - [Aktor Group](https://www.linkedin.com/company/aktorgroup) (Current) Jul 2022 - Present (4 years and 3 months) in Athens, Attica, Greece
value seen: https://gr.linkedin.com/in/alexandros-exarchou-019571364
https://gr.linkedin.com/in/alexandros-exarchou-019571364

Sources: role type

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Alexandros Exarchou is the Chairman and CEO of AKTOR Group of Companies, and CEO of ATLANTIC SEE LNG TRADE.
value seen: Chairman and CEO
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://aktor.gr/en/leadership/

Sources: since

SOCIALdate not shown in source

Alexandros Exarchou

LinkedIn
### Chairman and CEO - [Aktor Group](https://www.linkedin.com/company/aktorgroup) (Current) Jul 2022 - Present (4 years and 3 months) in Athens, Attica, Greece
value seen: Jul 2022 - Present
https://gr.linkedin.com/in/alexandros-exarchou-019571364

Sources: summary

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Exarchou has over 30 years’ experience in the construction of public projects in Greece and abroad. Apart from Greece, Mr. Exarchou has worked and managed projects in Europe, Middle East and North Africa.
value seen: over 30 years’ experience in the construction of public projects in Greece and abroad
value paraphrased from this source
https://aktor.gr/en/leadership/

Sources: title

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Mr. Alexandros Exarchou is the Chairman and CEO of AKTOR Group of Companies, and CEO of ATLANTIC SEE LNG TRADE.
value seen: Chairman and CEO of AKTOR Group of Companies; CEO of ATLANTIC SEE LNG TRADE
held out of the figures · the quote does not carry this value
https://aktor.gr/en/leadership/
AA
Anastasios Aranitis
Aranitis runs group operations and the construction and equity-participation subsidiaries. His documented track record covers complex infrastructure delivery, including metro, rail, roads, concessions and PPPs.
Current title
Group Chief Operating Officer; CEO, AKTOR CONSTRUCTION & AKTOR EQUITY PARTICIPATIONS
since Jan 2026 - Present
Experience
no career length stated
Companies before
METKA SAMYTILINEOS S.A.D. Kougioumtzopoulos S.A.AKTOR S.A.
Education
National Technical University of Athens (NTUA), School of Civil EngineeringDiploma in Civil Engineering
École Nationale des Ponts et Chaussées (ENPC)
Other boards
none sourced
Known for
nothing tagged
https://linkedin.com/in/anastasios-aranitis-b2a862202

Sources: degree

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Anastasios Aranitis is a Ph.D. candidate at the School of Civil Engineering of the National Technical University of Athens (NTUA), from which he received his Diploma in Civil Engineering in 1991.
value seen: Diploma in Civil Engineering
https://aktor.gr/en/leadership/

Sources: institution

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Anastasios Aranitis is a Ph.D. candidate at the School of Civil Engineering of the National Technical University of Athens (NTUA), from which he received his Diploma in Civil Engineering in 1991.
value seen: National Technical University of Athens (NTUA)
https://aktor.gr/en/leadership/

Sources: institution

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
He also studied at École Nationale des Ponts et Chaussées (ENPC) in Paris, France.
value seen: École Nationale des Ponts et Chaussées (ENPC)
https://aktor.gr/en/leadership/

Sources: full name

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Alexandros Exarchou assumes the role of Chairman and CEO, Mr. Anastasios Aranitis as Group Chief Operating Officer, Mr. Ioannis Argyropoulos as Group Chief Legal Officer, Mr. Konstantinos Adamopoulos as Group Chief Financial Officer, Mr. Georgios Syrianos as Group Chief Commercial Officer, Ms. Evita Tsartillidou as Group Chief of Staff.
value seen: Anastasios Aranitis
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: linkedin page

SOCIALdate not shown in source

Anastasios Aranitis

LinkedIn
### Chief Executive Officer, AKTOR CONSTRUCTION & AKTOR EQUITY PARTICIPATIONS - [Aktor Group](https://www.linkedin.com/company/aktorgroup) (Current) Jan 2026 - Present (8 months)
value seen: https://linkedin.com/in/anastasios-aranitis-b2a862202
https://linkedin.com/in/anastasios-aranitis-b2a862202

Sources: previous companies

SOCIALdate not shown in source

Anastasios Aranitis

LinkedIn
### Deputy Director of Infrastructure - METKA SA (Current) Jul 2022 - Mar 2026 (3 years and 8 months)
value seen: METKA SA
https://linkedin.com/in/anastasios-aranitis-b2a862202

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
During his professional career, he has served as Technical Director at AKTOR S.A. and Deputy Director of Infrastructure at MYTILINEOS S.A.
value seen: MYTILINEOS S.A.
https://aktor.gr/en/leadership/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Additionally, he was the owner and CEO of D. Kougioumtzopoulos S.A., a steel construction manufacturing facility, which experienced significant growth under his management.
value seen: D. Kougioumtzopoulos S.A.
https://aktor.gr/en/leadership/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
During his professional career, he has served as Technical Director at AKTOR S.A. and Deputy Director of Infrastructure at MYTILINEOS S.A.
value seen: AKTOR S.A.
https://aktor.gr/en/leadership/

Sources: role type

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Alexandros Exarchou assumes the role of Chairman and CEO, Mr. Anastasios Aranitis as Group Chief Operating Officer
value seen: Group Chief Operating Officer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: since

SOCIALdate not shown in source

Anastasios Aranitis

LinkedIn
### Chief Executive Officer, AKTOR CONSTRUCTION & AKTOR EQUITY PARTICIPATIONS - [Aktor Group](https://www.linkedin.com/company/aktorgroup) (Current) Jan 2026 - Present (8 months)
value seen: Jan 2026 - Present
https://linkedin.com/in/anastasios-aranitis-b2a862202

Sources: summary

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Anastasios has extensive experience in the construction and engineering sector, including the execution and management of complex, large-scale infrastructure projects. As Director Manager, he participates in AKTOR Group’s strategic planning, overseeing the achievement of corporate objectives in Greece and internationally.
value seen: extensive experience in the construction and engineering sector
value paraphrased from this source
https://aktor.gr/en/leadership/

Sources: title

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
– AKTOR CONSTRUCTIONS and AKTOR PARTICIPATIONS: Mr. Anastasios Aranitis
value seen: Group Chief Operating Officer; CEO, AKTOR CONSTRUCTION & AKTOR EQUITY PARTICIPATIONS
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/
KA
Konstantinos Adamopoulos
Adamopoulos oversees the Group’s financial management. His disclosed background spans National Bank of Greece, QUALCO, Credicom Bank and Piraeus Group, including strategic transactions, investor relations, M&A and recapitalisation work.
Current title
Group Chief Financial Officer
since July 2023
Experience
no career length stated
Companies before
National Bank of GreeceQUALCO GroupCredicom BankPiraeus Group
Education
not published
Other boards
none sourced
Known for
nothing tagged

Sources: full name

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Konstantinos Adamopoulos as Group Chief Financial Officer
value seen: Konstantinos Adamopoulos
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Before this role, he was Assistant General Manager and Head of Strategic transactions at the National Bank of Greece.(2019-2023)
value seen: National Bank of Greece
https://aktor.gr/en/leadership/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
He was a CFO at QUALCO Group (2018-2019), managing portfolio acquisitions, servicing €5bn NBG exposures, and advising on Attica Bank recapitalization.
value seen: QUALCO Group
https://aktor.gr/en/leadership/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
In 2017, he was CFO of Credicom Bank, designing the financial systems and leading strategic planning and capital increases.
value seen: Credicom Bank
https://aktor.gr/en/leadership/

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
Director of Strategy, IR & Economic Analysis, Piraeus Group (2013-2015)
value seen: Piraeus Group
https://aktor.gr/en/leadership/

Sources: role type

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Konstantinos Adamopoulos as Group Chief Financial Officer
value seen: Group Chief Financial Officer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: since

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
He assumed the role of the Group CFO at Aktor Group in July 2023, overseeing the financial management of the Group.
value seen: July 2023
https://aktor.gr/en/leadership/

Sources: summary

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
He assumed the role of the Group CFO at Aktor Group in July 2023, overseeing the financial management of the Group.
value seen: Group CFO at Aktor Group in July 2023
value paraphrased from this source
https://aktor.gr/en/leadership/

Sources: title

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Konstantinos Adamopoulos as Group Chief Financial Officer
value seen: Group Chief Financial Officer
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/
IA
Ioannis Argyropoulos
Argyropoulos is the Group’s chief legal officer and is named on the boards of the principal operating subsidiaries in the 2026 structure. No reliable independent career or education biography was found in the retrieved material.
Current title
Group Chief Legal Officer
Experience
no career length stated
Companies before
none sourced
Education
not published
Other boards
none sourced
Known for
nothing tagged

Sources: full name

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Ioannis Argyropoulos as Group Chief Legal Officer
value seen: Ioannis Argyropoulos
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: role type

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Ioannis Argyropoulos as Group Chief Legal Officer
value seen: Group Chief Legal Officer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: summary

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Ioannis Argyropoulos as Group Chief Legal Officer
value seen: Group Chief Legal Officer
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: title

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Ioannis Argyropoulos as Group Chief Legal Officer
value seen: Group Chief Legal Officer
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/
GS
Georgios Syrianos
Syrianos is Group Chief Commercial Officer and is independently identified as CEO of AKTOR Concessions. He is a civil engineer with a long infrastructure and concessions record spanning motorways, rail, tunnels, dams, ports, wastewater and Olympic projects.
Current title
Group Chief Commercial Officer
Experience
no career length stated
Companies before
none sourced
Education
National Technical University of Athens (NTUA)Civil Engineering degree
Other boards
President, Association of Technical Companies of the Highest Classes (STEAT)Member, Governing Committee of the National Technical University of Athens (NTUA)
Known for
nothing tagged

Sources: degree

PRESSdate not shown in source

Georgios Syrianos – ITC 2025 – 8th Infrastructure & Transport Conference

ITC Greece
He is Civil Engineer, holding a degree from the National Technical University of Athens (NTUA).
value seen: Civil Engineering degree
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://itcgreece.gr/en/speakers/giorgos-syrianos/

Sources: institution

PRESSdate not shown in source

Georgios Syrianos – ITC 2025 – 8th Infrastructure & Transport Conference

ITC Greece
He is Civil Engineer, holding a degree from the National Technical University of Athens (NTUA).
value seen: National Technical University of Athens (NTUA)
https://itcgreece.gr/en/speakers/giorgos-syrianos/

Sources: full name

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Georgios Syrianos as Group Chief Commercial Officer
value seen: Georgios Syrianos
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: other boards

PRESSdate not shown in source

Georgios Syrianos – ITC 2025 – 8th Infrastructure & Transport Conference

ITC Greece
He is the President of the Association of Technical Companies of the Highest Classes (STEAT), member of the Governing Committee of the National Technical University of Athens (NTUA), and he has served as member of the Board of Directors of the Athens Chamber of Commerce and Industry (ACCI).
value seen: President, Association of Technical Companies of the Highest Classes (STEAT)
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://itcgreece.gr/en/speakers/giorgos-syrianos/

Sources: other boards

PRESSdate not shown in source

Georgios Syrianos – ITC 2025 – 8th Infrastructure & Transport Conference

ITC Greece
He is the President of the Association of Technical Companies of the Highest Classes (STEAT), member of the Governing Committee of the National Technical University of Athens (NTUA), and he has served as member of the Board of Directors of the Athens Chamber of Commerce and Industry (ACCI).
value seen: Member, Governing Committee of the National Technical University of Athens (NTUA)
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://itcgreece.gr/en/speakers/giorgos-syrianos/

Sources: role type

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Georgios Syrianos as Group Chief Commercial Officer
value seen: Group Chief Commercial Officer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: summary

PRESSdate not shown in source

Georgios Syrianos – ITC 2025 – 8th Infrastructure & Transport Conference

ITC Greece
He is currently the Chief Executive Officer (CEO) of AKTOR Concessions S.A. and is directly involved in the execution of large and complex Concessions and PPP Projects.
value seen: currently the Chief Executive Officer (CEO) of AKTOR Concessions S.A.
value paraphrased from this source
https://itcgreece.gr/en/speakers/giorgos-syrianos/

Sources: title

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Mr. Georgios Syrianos as Group Chief Commercial Officer
value seen: Group Chief Commercial Officer
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/
ET
Evita Tsartillidou
Tsartillidou is Group Chief of Staff, with a documented focus on strategic initiatives and organisational improvement. She has more than 27 years in construction-sector leadership, including contracts, claims and risk work at AKTOR and senior roles at Intrakat and Hill International.
Current title
Group Chief of Staff
since Jan 2026 - Present
Experience
no career length stated
Companies before
Intrakat GroupHill InternationalAKTOR Group
Education
Imperial College LondonMaster of Science (MSc), Concrete Structures
Other boards
none sourced
Known for
nothing tagged
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: degree

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
### Master of Science (MSc), Concrete Structures at Imperial College London
value seen: Master of Science (MSc), Concrete Structures
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: institution

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
### Master of Science (MSc), Concrete Structures at Imperial College London
value seen: Imperial College London
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: full name

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Ms. Evita Tsartillidou as Group Chief of Staff
value seen: Evita Tsartillidou
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: linkedin page

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
#### Chief of Staff at Aktor Group (Current) Jan 2026 - Present (3 months) in Athens
value seen: https://linkedin.com/in/evita-tsartilidou-aa2b1058
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: previous companies

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
Previous senior roles at Intrakat Group (Chief of Staff, Director) and Hill International (Contracts Director),involved in major projects including the Hellinikon works.
value seen: Intrakat Group
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: previous companies

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
Previous senior roles at Intrakat Group (Chief of Staff, Director) and Hill International (Contracts Director),involved in major projects including the Hellinikon works.
value seen: Hill International
https://linkedin.com/in/evita-tsartillididou-aa2b1058

Sources: previous companies

COMPANY2024-11-27

Aktor Group | Leadership Team

Aktor Group
She also worked at AKTOR from 1998 to 2021, holding leadership positions from 2017 to 2021, including Head of Contracts Management, where she oversaw claims and risks for international and domestic projects.
value seen: AKTOR Group
held out of the figures · the quote does not carry this value
https://aktor.gr/en/leadership/

Sources: role type

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Ms. Evita Tsartillidou as Group Chief of Staff
value seen: Group Chief of Staff
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Sources: since

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
#### Chief of Staff at Aktor Group (Current) Jan 2026 - Present (3 months) in Athens
value seen: Jan 2026 - Present
https://linkedin.com/in/evita-tsartilididou-aa2b1058

Sources: summary

SOCIALdate not shown in source

Evita Tsartillidou

LinkedIn
•Over 27 years of continuous experience in the construction sector, with expertise in project management, contracts management, and corporate leadership. •Chief of AKTOR Group of Companies, leading strategic initiatives and organizational improvements. •Previous senior roles at Intrakat Group (Chief of Staff, Director) and Hill International (Contracts Director),involved in major projects including the Hellinikon works.
value seen: Over 27 years of continuous experience in the construction sector
value paraphrased from this source
https://linkedin.com/in/evita-tsartilidou-aa2b1058

Sources: title

PRESS2026-02-05

AKTOR Group unveils new organizational structure and vertical business model

Parapolitika
Ms. Evita Tsartillidou as Group Chief of Staff
value seen: Group Chief of Staff
https://en.parapolitika.gr/economy/147693/aktor-group-unveils-new-organizational-structure-and-vertical-business-model/

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases
The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

4 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
Ippokratous 3-5Athens, Greece
office, retail—97,300 m²——20202020—Dec 2022—not scorablecompleted
Xenodocheio MilosAthens, Greece
Παλιά Βουλή
hotel42154,489 m²——201718/10/2017Jan 2022 – Dec 2022Jan 2022 – Dec 20220.0 mo
(−11.0 to +11.0)
estimatedcompleted
Villa AiliaMykonos, Greece
Kalo Livadi
other—5—————Jul 2018Jan 2021 – Dec 2021dates under reviewdates under reviewcompleted
Branco MykonosMykonos, Greece
Platis Gialos
hotel211————2017June 2017Jan 2017 – Dec 2017Jun 2017−0.5 mo
(−6.0 to +5.0)
sourcedcompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

4 found
PROJECT AWARD Winner 2024-10-07 (reported)
Special Award — Construction Project of the Year 2023 · Riviera Tower, Elliniko
The BOUYGUES–INTRAKAT joint venture was reported as receiving the special award for the Riviera Tower project, recognising more than 40 continuous hours of raft-foundation concrete pouring and a reported Greek record.
Infrastructure & Transport Conference (ITC 2024) · https://www.linkedin.com/feed/update/urn:li:activity:7249115782347972608
COMPANY AWARD Winner 2023
Protagonists of the Greek Economy 2023 — Development and Investment
The developer reports receiving the 2023 award in the Development and Investment category, an institution described as recognising businesses supporting the Greek economy based on published financial data and market assessment.
PROJECT AWARD Winner 2021-07-01 (reported; award for 2019)
Project of the Year 2019 · Thessaloniki Airport “Makedonia” upgrade
Intrakat and Fraport Greece were named recipients of the Project of the Year 2019 award for the upgrade of Thessaloniki Airport “Makedonia,” presented by Greece’s Minister of Infrastructure and Transport.
SUSTAINABILITY Certified 2024-03-02 (reported)
BREEAM In-Use International Commercial V6 — Very Good · Ippokratous 3–5 office and retail building, Athens
The developer’s refurbished office building at Ippokratous 3–5 was reported as receiving BREEAM “Very Good” environmental-performance certification; the project page identifies the building as an Aktor property.

Risks

Risk flags

4 found
PROJECT CANCELLED 11 November 2024 (termination reported); project was reported as about 30% complete
On 11 November 2024, Cyprus’s Public Works Department terminated Intrakat’s contract for Phase 1 of the Paphos–Polis Chrysochous highway, citing significant and unjustified contractor delays; the department said the contractor had completed about 30% and would be replaced through a new tender. Intrakat disputed responsibility, attributing the impasse to excavation, materials, disposal-site and government-response problems, and sought damages through the courts.
DELIVERY DELAY 4 March 2023 (status reported); original deadline 2016; fiscal correction validated 26 June 2019
A 2014 rail-signalling contract involving TOMI, an Ellaktor subsidiary, and Alstom—covering work attributed in reporting to the Aktor/Alstom consortium—missed its 2016 deadline, received successive extensions and had stalled; an audit validated in 2019 required recovery of €2.42 million from project manager ERGOSE for deficient studies and failure to provide required know-how, while a €13.3 million supplementary contract was signed in 2022 and the system was still not operational when reported in March 2023.
REGULATORY 10 March 2017 (decision published); conduct covered 2005–2012
In a final 10 March 2017 settlement decision, the Hellenic Competition Commission found that Intrakat and other contractors had accepted participation in a 2005–2012 public-works bid-rigging and market-allocation scheme and imposed a €4,300,493 fine on Intrakat; the decision records that the infringement finding was not appealed.
DELIVERY DELAY 28 January 2026 (status report); May 2026 permits; 2028 reported completion target
The Alimos Marina redevelopment, implemented by REDS (an Ellaktor subsidiary and, since the 2025 acquisition of Aktor Concessions, within the broader Aktor Group perimeter), remained materially delayed: a January 2026 report said the site was essentially stalled and completion had shifted to May 2028, while later 2026 reporting said permits were finally issued and construction was only planned to start in 2026; this is a delayed project, not an abandoned one.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 10, 2026 this month
Profile last researchedOctober 10, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.