Artificial Intelligence
Builders Company
Developers/BioMed Realty
BR
BioMed RealtySan Diego, United States · founded April 30, 2004 · 2 active markets
PRIVATE

BioMed Realty develops, owns, and operates purpose-built laboratory, office, and innovation spaces across leading U.S. and U.K. life-science hubs. Its tenants include biotechnology, pharmaceutical, technology, research, and other innovation-driven organizations needing specialized infrastructure, flexible environments, and long-term operational support services.

Years in business
22
founded April 30, 2004
LinkedIn headcount
393
employees, as shown on LinkedIn · size band 201–500
Portfolio value
USD 22 billion
August 21, 2024
Projects last researched October 11, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
BioMed Realty, L.P.1
Headquarters
4570 Executive Drive, Suite 4001, San Diego1, United States
Founded
April 30, 20041
Entity type
PRIVATE1
Business model
commercial1
Markets
2 markets listed
What they build
Office (10 of 10) · Other (6 of 10) · Industrial (4 of 10)
Full dossier in About →

Delivery record

9 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
+1.5 mo
the middle of 9 scored projects
Average delay
+7.1 mo
the same projects, pulled by the worst
Average time to deliver
3.5 yrs
start to completion, over 7 delivered projects
Worst slip
+20.0 mo
Dexter Yard · +13.0 to +27.0
5
early or less than 6 months late
6 to 12 months late
1
yellow rows below
Over 12 months late
3
red rows below

Against other developers

9 date-assessed here · 236 developers, 871 date-assessed projects in United States
Median delay
BioMed Realty·236 developers in United States
+1.5 mo vs +4.5 mo
this developer 3.0 mo better
The typical project on each side.
Average delay
BioMed Realty·236 developers in United States
+7.1 mo vs +7.6 mo
this developer 0.5 mo better
Both pulled by their worst few.
On time
BioMed Realty·236 developers in United States
56% vs 55%
this developer 1 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
BioMed Realty·236 developers in United States
3.5 yrs vs 2.9 yrs
this developer 0.6 yrs slower
Start to completion, over 7 delivered here and 718 in the market.
Projects and timelines in Track Record →

Resident experience

2 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.2/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (0 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
—/ 10
Fabric, services, waterproofing, envelope · from 0 of 2 rated buildings
Management & living
8.2/ 10
Upkeep, response times, amenities, community · from 2 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in United States yet to compare against.
Ratings by building →

Awards & recognition

  • PROJECT AWARD Winner 2026
    The Outstanding Building of the Year (TOBY) Award — Life Science Building · Gateway of Pacific
    Gateway of Pacific in South San Francisco won the 2026 international TOBY Award in the Life Science Building category; BOMA identifies BioMed Realty as both manager and owner.
  • RANKING Ranked 2025 results, reported December 23, 2025
    GRESB Real Estate Assessment — first place in the Development Benchmark, Technology/Science/Non-listed/Core, Americas
    The Blackstone Core+ Life Sciences Real Estate strategy, which includes BioMed Realty, ranked first in the specified 2025 GRESB Development Benchmark for the second consecutive year and received a 4-Star rating in both Standing Assets and Development Assets.
  • COMPANY AWARD May 14, 2025
    Fitwel Champion Company
    Fitwel recognized BioMed Realty as a Fitwel Champion Company for leadership in promoting health and wellness through the built environment across its portfolio.
  • 4 more in Awards
All awards →

Risks & source coverage

  • DELIVERY DELAY Reported September 17, 2024; the article described the site as undeveloped and the opening as pushed to 2025. Towne Centre View, a BioMed Realty project in San Diego, remained undeveloped when reported in September 2024, with its opening date pushed back to 2025 and the precise timeline described as unclear; BioMed said it was still discussing prospective tenants.
  • SAFETY / LABOUR Liens reported as filed in 2020; source published September 16, 2020 and updated July 30, 2021. At BioMed Realty’s Gateway of Pacific project, four subcontractors filed mechanics liens alleging unpaid construction work totaling $11,452,002.50; one subcontractor also alleged non-payment, withheld funds and project delays by the general contractor, Turner Construction. The source does not establish that BioMed itself owed the subcontractors, and it records a lien-release bond for one claim.
  • LEGAL Complaint filed September 24, 2025; reported September 30, 2025. BioMed Realty sued SmartLabs alleging breach of contract and approximately $2.7 million in unpaid rent and fees at a Cambridge property; the report said the complaint was filed September 24, 2025, and that SmartLabs had not yet responded, so the allegations were unresolved as of publication.
  • 3 more in Risk & Sources
Record status
active
Company sources
117 source entries across 117 fields
Projects tracked
10 · 10 completed in assessment
All flags and sources →

Track Record

Delivery record

9 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
+1.5 mo
the middle of 9 scored projects
Average delay
+7.1 mo
the same projects, pulled by the worst
Average time to deliver
3.5 yrs
start to completion, over 7 delivered projects
Worst slip
+20.0 mo
Dexter Yard · +13.0 to +27.0
5
early or less than 6 months late
6 to 12 months late
1
yellow rows below
Over 12 months late
3
red rows below

Against other developers

9 date-assessed here · 236 developers, 871 date-assessed projects in United States
Median delay
BioMed Realty·236 developers in United States
+1.5 mo vs +4.5 mo
this developer 3.0 mo better
The typical project on each side.
Average delay
BioMed Realty·236 developers in United States
+7.1 mo vs +7.6 mo
this developer 0.5 mo better
Both pulled by their worst few.
On time
BioMed Realty·236 developers in United States
56% vs 55%
this developer 1 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
BioMed Realty·236 developers in United States
3.5 yrs vs 2.9 yrs
this developer 0.6 yrs slower
Start to completion, over 7 delivered here and 718 in the market.
The market here is United States: every other developer whose head office is in the same country, because planning regimes and reporting norms move together within one. It is not a city, a sector or a size band. Read the two delay figures together. A median close to the market with a much better average means no single disaster; the reverse means one project is carrying the record. Time to deliver runs from the earliest start we hold to the completion itself — a construction start where a source gave one, otherwise a sales launch, otherwise the launch year read as its January. A handover the sources place only inside a year is read as that December, so a duration is the widest the record allows rather than the flattering end of it. Only delivered projects dated at both ends count, so it is taken over fewer projects than the delay figures, and a long build is not a fault: a tower is not a villa run. Sourced figures only, both sides, and values taken from documents held on file are excluded here — a developer who shares their records should not score better than one who does not.

Construction start to handover

10 of 10 projects dated · 8 places
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
Emeryville, United States
Cambridge, United Kingdom
Boulder, United States
Somerville, United States
Seattle, United States
South San Francisco, United States
San Diego, United States
La Jolla, United States
201320142015201620172018201920202021202220232024202520262027todayEMERYVILLE, UNITED STATES+15 moestimatedCAMBRIDGE, UNITED KINGDOM+1 moverifiedon timeverifiedBOULDER, UNITED STATES+1.5 moverifiedSOMERVILLE, UNITED STATES−1 moverifiedSEATTLE, UNITED STATES+20 moverifiedSOUTH SAN FRANCISCO, UNITED STATES+19.5 moverified+16.5 moverifiedSAN DIEGO, UNITED STATESon timeverifiedLA JOLLA, UNITED STATES+6.5 moverified
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures. 1 turned out to be about something else — a phase, a neighbour, the wider masterplan — and is marked off-subject.

Building & Livability Ratings

Resident experience

2 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.2/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (0 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
—/ 10
Fabric, services, waterproofing, envelope · from 0 of 2 rated buildings
Management & living
8.2/ 10
Upkeep, response times, amenities, community · from 2 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in United States yet to compare against.

By building

2 rated · 8 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
Gateway of Pacific Phase IIIEast Side, South San Francisco
8.8/ 10
—/ 10
8.8/ 10

The only located published aggregate is 4.6/5 from 12 reviews for the Gateway of Pacific listing; because it is a cluster-level listing rather than an unambiguous Phase III-only listing, it is reported with CLUSTER scope and used cautiously as the anchor. Applying the stated conversion curve gives 8.8/10, while structure remains unevidenced by review material. Construction reporting says Phase III was wrapping up in December 2021, and current campus material identifies GOP III at 700 Gateway Boulevard as available, but those are status or marketing evidence rather than resident-review scores.

+ Attractive exterior+ Business-park setting+ Campus amenity center+ Transit and commuter options

no notes returned

no links returned

The available review material is sparse and does not describe management, staff, security, or maintenance in detail. The two visible comments are favorable: one says the exterior is “beautiful,” while the other simply calls it a “bussiness park”; the campus page separately describes a 50,000-square-foot amenity center and multiple commuter options, but those are developer-published features rather than resident reviews.

Dexter YardSouth Lake Union, Seattle
7.5/ 10
—/ 10
7.5/ 10
Guided Fitness 4.5/5 · 6 reviews · guidedfitness.com
Guided Fitness publishes 4.5/5 from 6 reviews. Adjusted for where resident ratings usually fall, and weighted toward the 6.5 midpoint (more strongly the fewer the reviews), that gives 7.5.

Guided Fitness is the only located building-specific aggregate: a 4.5/5 facility rating from 6 reviews, which converts to 8.5/10 but must remain within one point of 6.5 because it has fewer than 10 reviews; the capped anchor used here is 7.5. One repeated minor comfort complaint moves the reported overall and living score to 7.3. No published material supports a structure score.

+ Convenient location+ Attractive facility+ Functional gym space
− Variable temperature− Background noise− Access difficulty− Staff activity distracting during class

no notes returned

no links returned

Guided Fitness users described Dexter Yard’s facility as “very beautiful” and “very functional,” and one called the location “very convenient.” Operational criticisms included that “all of the doors were locked,” “lots of random noises and people passing through,” and a staff member changing equipment during a class was “a little distracting.” These are fitness-facility reviews, not resident housing reviews; Dexter Yard is published as a life-science and office campus rather than a residential building.

Only buildings that have reached handover are rated. 8 of 10 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
BioMed Realty, L.P.
Headquarters
4570 Executive Drive, Suite 400, San Diego, United States
92121
Founded
April 30, 2004
Entity type
PRIVATE
Revenue
USD 45.3 million
Business model
commercial

Offices

head office and 5 others
CambridgeSouth San FranciscoSeattleBoulderCambridge

Sources: office cities

COMPANYdate not shown in source

Contact Us - BioMed Realty

BioMed Realty
314 Main Street 14th Floor Cambridge, MA 02142
value seen: Cambridge
value paraphrased from this source
https://www.biomedrealty.com/company/contact-us

Sources: office cities

COMPANYdate not shown in source

Contact Us - BioMed Realty

BioMed Realty
700 Gateway Blvd Suite 100 South San Francisco, CA 94080
value seen: South San Francisco
value paraphrased from this source
https://www.biomedrealty.com/company/contact-us

Sources: office cities

COMPANYdate not shown in source

Contact Us - BioMed Realty

BioMed Realty
700 Dexter Avenue North Suite 250 Seattle, WA 98109
value seen: Seattle
value paraphrased from this source
https://www.biomedrealty.com/company/contact-us

Sources: office cities

COMPANYdate not shown in source

Contact Us - BioMed Realty

BioMed Realty
2108 55th Street Suite 200 Boulder, CO 80301
value seen: Boulder
value paraphrased from this source
https://www.biomedrealty.com/company/contact-us

Sources: office cities

COMPANYdate not shown in source

Contact Us - BioMed Realty

BioMed Realty
The Cricket Pavilion Granta Park, Great Abington Cambridge CB21 6GP, UK
value seen: Cambridge
value paraphrased from this source
https://www.biomedrealty.com/company/contact-us

Partners

3 partners
Babraham Research Campus Ltd
joint venture

BioMed Realty and Babraham Research Campus Ltd operate a joint venture that develops and manages the Babraham Research Campus.

BBSRC–UKRI
government partner

BBSRC–UKRI is identified as a shareholder of Babraham Research Campus Ltd, the campus partner in BioMed Realty’s joint venture.

Babraham Institute
partner

The Babraham Institute is identified as a shareholder of Babraham Research Campus Ltd, the campus partner in BioMed Realty’s joint venture.

Sources: name

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the success of our long-standing joint venture with Babraham Research Campus Ltd
value seen: Babraham Research Campus Ltd
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: partner type

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
another milestone in the joint venture between BioMed Realty and Babraham Research Campus Ltd
value seen: JV_PARTNER
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: summary

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the joint venture between BioMed Realty and Babraham Research Campus Ltd (BRC Ltd), which develops and manages the Campus on behalf of its shareholders, BBSRC–UKRI and the Babraham Institute.
value seen: BioMed Realty and Babraham Research Campus Ltd operate a joint venture that develops and manages the Babraham Research Campus.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: name

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
BBSRC–UKRI and the Babraham Institute
value seen: BBSRC–UKRI
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: partner type

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the joint venture between BioMed Realty and Babraham Research Campus Ltd (BRC Ltd), which develops and manages the Campus on behalf of its shareholders, BBSRC–UKRI and the Babraham Institute.
value seen: GOVERNMENT_PARTNER
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: summary

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the joint venture between BioMed Realty and Babraham Research Campus Ltd (BRC Ltd), which develops and manages the Campus on behalf of its shareholders, BBSRC–UKRI and the Babraham Institute.
value seen: BBSRC–UKRI is identified as a shareholder of Babraham Research Campus Ltd, the campus partner in BioMed Realty’s joint venture.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: name

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
BBSRC–UKRI and the Babraham Institute
value seen: Babraham Institute
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: partner type

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the joint venture between BioMed Realty and Babraham Research Campus Ltd (BRC Ltd), which develops and manages the Campus on behalf of its shareholders, BBSRC–UKRI and the Babraham Institute.
value seen: OTHER
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Sources: summary

PRESS2026-02-24

BioMed Realty and Babraham Research Campus Ltd Complete Lease-Up of Newest Building at Babraham Research Campus, with TRIMTECH Therapeutics and Tagomics

Business Wire
the joint venture between BioMed Realty and Babraham Research Campus Ltd (BRC Ltd), which develops and manages the Campus on behalf of its shareholders, BBSRC–UKRI and the Babraham Institute.
value seen: The Babraham Institute is identified as a shareholder of Babraham Research Campus Ltd, the campus partner in BioMed Realty’s joint venture.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.businesswire.com/news/home/20260224365894/en/BioMed-Realty-and-Babraham-Research-Campus-Ltd-Complete-Lease-Up-of-Newest-Building-at-Babraham-Research-Campus-with-TRIMTECH-Therapeutics-and-Tagomics

Registrations & licences

OTHER0001301932
U.S. Securities and Exchange Commission · US
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

2 countries
United Statesactive 8 projects tracked
United Kingdomactive 2 projects tracked

What they build

6 types
Office10 of 10
Other6 of 10
Industrial4 of 10
Masterplan1 of 10
Retail1 of 10
Mixed use1 of 10
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
TS
Tim Schoen
Tim Schoen has served as BioMed Realty’s CEO since 2016, leading its growth in life-science real estate. Before BioMed, he was CFO of Healthpeak and held corporate-finance leadership at Kilroy Realty.
Current title
Chief Executive Officer
since since 2016
Experience
no career length stated
Companies before
HealthpeakKilroy Realty Corporation
Education
Minnesota State UniversityBS in finance and international business
University of California, IrvineMBA
Other boards
Board of Trustees, Salk Institutechair, Salk’s Conquering Cancer Initiative Advisory Committee
Known for
CEO17 million square feetHealthpeakKilroy Realty
As we enter our third decade, our core mission has remained the same: to provide life science and technology companies with world-class innovation space, so they can continue to advance human health. BioMed Realty August 21, 2024https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Mr. Schoen received a BS in finance and international business from Minnesota State University and earned his MBA from the University of California, Irvine’s Paul Merage School of Business.
value seen: Minnesota State University — BS in finance and international business; University of California, Irvine — MBA
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Tim Schoen - CEO of BioMed Realty](https://www.biomedrealty.com/wp-content/uploads/2025/09/tim-schoen-square.webp)
value seen: Tim Schoen
https://www.biomedrealty.com/company/leadership

Sources: other boards

PRESS2020-05-15

Podcast: Tim Schoen, CEO of BioMed Realty

The Registry
Tim has been BioMed’s CEO since 2016, when he joined the company following its acquisition by Blackstone Group. He currently serves on the Board of Trustees for the Salk Institute in San Diego and is also the chair of Salk’s Conquering Cancer Initiative Advisory Committee.
value seen: Board of Trustees, Salk Institute; chair, Salk’s Conquering Cancer Initiative Advisory Committee
held out of the figures · the quote does not carry this value
https://news.theregistrysf.com/podcast-tim-schoen-ceo-of-biomed-realty/

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Prior to joining BioMed Realty, Mr. Schoen was Executive Vice President and Chief Financial Officer of Healthpeak, an S&P 500 real estate company, from 2011 to 2016. Mr. Schoen served as Vice President of Corporate Finance at Kilroy Realty Corporation for nine years before his time at Healthpeak.
value seen: Healthpeak; Kilroy Realty Corporation
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: date

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate
value seen: August 21, 2024
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: publisher

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
said BioMed Realty’s Chief Executive Officer Tim Schoen.
value seen: BioMed Realty
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: quote

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
As we enter our third decade, our core mission has remained the same: to provide life science and technology companies with world-class innovation space, so they can continue to advance human health.
value seen: As we enter our third decade, our core mission has remained the same: to provide life science and technology companies with world-class innovation space, so they can continue to advance human health.
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Chief Executive Officer
value seen: CEO
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Tim Schoen has served as BioMed’s CEO since 2016.
value seen: since 2016
https://www.biomedrealty.com/company/leadership

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Tim Schoen has served as BioMed’s CEO since 2016. Under Mr. Schoen’s leadership, BioMed Realty has grown its portfolio, including development to 17 million square feet across six core markets.
value seen: Tim Schoen has served as BioMed Realty’s CEO since 2016, leading its growth in life-science real estate. Before BioMed, he was CFO of Healthpeak and held corporate-finance leadership at Kilroy Realty.
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Prior to joining BioMed Realty, Mr. Schoen was Executive Vice President and Chief Financial Officer of Healthpeak, an S&P 500 real estate company, from 2011 to 2016.
value seen: CEO; 17 million square feet; Healthpeak; Kilroy Realty
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Chief Executive Officer
value seen: Chief Executive Officer
https://www.biomedrealty.com/company/leadership
JB
Jonathan Bergschneider
Jonathan Bergschneider leads BioMed Realty’s West Coast development, leasing and operations, including San Diego, San Francisco, Seattle and Boulder. He previously led life-sciences work at HCP and held leasing/development roles at Slough Estates and Draper and Kramer.
Current title
President - West Coast Markets
since since January 2021
Experience
14+ years
Companies before
HCP, Inc.Slough Estates USA, Inc.Draper and Kramer, Incorporated
Education
University of Illinois at Urbana-ChampaignBachelor of Arts in Economics
Other boards
none sourced
Known for
West CoastdevelopmentleasingHCP
https://linkedin.com/in/jon-bergschneider-847b698
From the development of our largest purpose-built campuses to our move-in ready Velocity lab space, these environments enable our clients to immediately begin R&D efforts upon moving in, with our goal to help accelerate therapies and treatments into the market. BioMed Realty August 21, 2024https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
He holds a Bachelor of Arts in Economics from the University of Illinois at Urbana-Champaign.
value seen: University of Illinois at Urbana-Champaign — Bachelor of Arts in Economics
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
## Jonathan Bergschneider
value seen: Jonathan Bergschneider
https://www.biomedrealty.com/company/leadership

Sources: linkedin page

SOCIAL2026-08-26

Jon Bergschneider

The Registry · carried by linkedin.com
President, West Coast Markets at BioMed Realty (Current)
value seen: https://linkedin.com/in/jon-bergschneider-847b698
https://linkedin.com/in/jon-bergschneider-847b698

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before joining BioMed Realty, Bergschneider was the Senior Managing Director of Life Sciences at HCP, Inc., for 14 years. He also previously oversaw leasing and development at Slough Estates USA, Inc., and worked at Draper and Kramer, Incorporated.
value seen: HCP, Inc.; Slough Estates USA, Inc.; Draper and Kramer, Incorporated
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: date

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate
value seen: August 21, 2024
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: publisher

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
said BioMed Realty’s Chief Executive Officer Tim Schoen.
value seen: BioMed Realty
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: quote

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
From the development of our largest purpose-built campuses to our move-in ready Velocity lab space, these environments enable our clients to immediately begin R&D efforts upon moving in, with our goal to help accelerate therapies and treatments into the market.
value seen: From the development of our largest purpose-built campuses to our move-in ready Velocity lab space, these environments enable our clients to immediately begin R&D efforts upon moving in, with our goal to help accelerate therapies and treatments into the market.
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### President - West Coast Markets
value seen: OTHER
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Jonathan M. Bergschneider has been the President of West Coast Markets since January 2021, where he leads development, leasing and operations.
value seen: since January 2021
https://www.biomedrealty.com/company/leadership

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Jonathan M. Bergschneider has been the President of West Coast Markets since January 2021, where he leads development, leasing and operations. He has guided the company’s growth in the San Diego, San Francisco, Seattle and Boulder markets.
value seen: Jonathan Bergschneider leads BioMed Realty’s West Coast development, leasing and operations, including San Diego, San Francisco, Seattle and Boulder. He previously led life-sciences work at HCP and held leasing/development roles at Slough Estates and Draper and Kramer.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before joining BioMed Realty, Bergschneider was the Senior Managing Director of Life Sciences at HCP, Inc., for 14 years.
value seen: West Coast; development; leasing; HCP; 14 years
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### President - West Coast Markets
value seen: President - West Coast Markets
https://www.biomedrealty.com/company/leadership
WK
William Kane
William Kane leads BioMed Realty’s East Coast and UK markets, where he has driven portfolio expansion and leasing/development across several major US regions. Before BioMed, he managed R&D, hospital and office development projects for four real-estate and construction companies.
Current title
President - East Coast & UK Markets
since since January 2021
Experience
20+ years
Companies before
The Fallon CompanyDavis Marcus PartnersLyme PropertiesTurner Construction
Education
Tufts UniversityBachelor of Science
Boston UniversityMaster of Business Administration
Boston UniversityMaster of Science
Other boards
none sourced
Known for
East Coast & UKportfolio expansiondevelopment
https://www.linkedin.com/in/williamkane
The life science industry is constantly changing, and to best serve our tenants, we are dedicated to evolving alongside it. BioMed Realty August 21, 2024https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Mr. Kane holds a Bachelor of Science from Tufts University and both a Master of Business Administration and Master of Science from Boston University.
value seen: Tufts University — Bachelor of Science; Boston University — MBA and Master of Science
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
## William Kane
value seen: William Kane
https://www.biomedrealty.com/company/leadership

Sources: linkedin page

SOCIAL2026-10-05

Bill Kane

The Registry · carried by linkedin.com
President, East Coast & UK Markets at BioMed Realty (Current)
value seen: https://www.linkedin.com/in/williamkane
https://www.linkedin.com/in/williamkane

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before joining BioMed Realty in 2008, Kane managed R&D, hospital, and office development projects for the Fallon Company, Davis Marcus Partners, Lyme Properties, and Turner Construction.
value seen: The Fallon Company; Davis Marcus Partners; Lyme Properties; Turner Construction
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: date

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate
value seen: August 21, 2024
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: publisher

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
said BioMed Realty’s Chief Executive Officer Tim Schoen.
value seen: BioMed Realty
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: quote

COMPANY2024-08-21

BioMed Realty Celebrates 20 Years of Delivering Mission-Critical Life Science Real Estate

BioMed Realty
The life science industry is constantly changing, and to best serve our tenants, we are dedicated to evolving alongside it.
value seen: The life science industry is constantly changing, and to best serve our tenants, we are dedicated to evolving alongside it.
https://www.biomedrealty.com/biomed-realty-celebrates-20-years-of-delivering-mission-critical-life-science-real-estate

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### President - East Coast and United Kingdom Markets
value seen: OTHER
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
William (Bill) Kane has been the President of East Coast and UK Markets since January 2021, following two years as Executive Vice President for those regions.
value seen: since January 2021
https://www.biomedrealty.com/company/leadership

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
William (Bill) Kane has been the President of East Coast and UK Markets since January 2021, following two years as Executive Vice President for those regions. He has led significant expansion of BioMed’s portfolio in these areas.
value seen: William Kane leads BioMed Realty’s East Coast and UK markets, where he has driven portfolio expansion and leasing/development across several major US regions. Before BioMed, he managed R&D, hospital and office development projects for four real-estate and construction companies.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
With two decades of experience, he has led leasing and development across Massachusetts, New York, New Jersey, and Pennsylvania.
value seen: East Coast & UK; 20+ years; portfolio expansion; development
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### President - East Coast and United Kingdom Markets
value seen: President - East Coast & UK Markets
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership
JL
John Lee
John Lee oversees BioMed Realty’s investment and asset-management functions, including sourcing growth and enhancing the existing portfolio. He brought more than 20 years in global commercial real estate after leading opportunistic real-estate asset management at PIMCO.
Current title
Executive Vice President & Chief Operating Officer
since September 2024
Experience
20+ years
Companies before
PIMCOCanyon PartnersO’Connor Capital PartnersTrammell Crow CompanyBain and Company
Education
University of California, Los AngelesBachelor of Arts in Business-Economics
Harvard Business SchoolMaster of Business Administration
Other boards
none sourced
Known for
COOinvestmentasset managementPIMCO

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Mr. Lee holds a Bachelor of Arts degree in Business-Economics from the University of California, Los Angeles and a Master of Business Administration degree from Harvard Business School.
value seen: University of California, Los Angeles — Bachelor of Arts in Business-Economics; Harvard Business School — Master of Business Administration
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
## John Lee
value seen: John Lee
https://www.biomedrealty.com/company/leadership

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Prior to joining PIMCO in 2013, Mr. Lee was an executive for several years within the private real estate group at Canyon Partners, after holding investment positions with O’Connor Capital Partners, Trammell Crow Company, and Bain and Company.
value seen: PIMCO; Canyon Partners; O’Connor Capital Partners; Trammell Crow Company; Bain and Company
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & Chief Operating Officer
value seen: COO
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
John Lee joined BioMed Realty as Executive Vice President and Chief Operating Officer in September 2024.
value seen: September 2024
https://www.biomedrealty.com/company/leadership

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
John Lee joined BioMed Realty as Executive Vice President and Chief Operating Officer in September 2024. He brings more than 20 years of leadership experience in global commercial real estate, he oversees the company’s Investment and Asset management functions.
value seen: John Lee oversees BioMed Realty’s investment and asset-management functions, including sourcing growth and enhancing the existing portfolio. He brought more than 20 years in global commercial real estate after leading opportunistic real-estate asset management at PIMCO.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before joining, Mr. Lee was the Global Head of Asset Management for PIMCO’s opportunistic real estate and private debt businesses.
value seen: COO; investment; asset management; PIMCO; 20+ years
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & Chief Operating Officer
value seen: Executive Vice President & Chief Operating Officer
https://www.biomedrealty.com/company/leadership
AP
Ankit Patel
Ankit Patel leads BioMed Realty’s financial reporting, accounting, planning, tax, treasury, capital markets, IT and asset-management functions. He brings healthcare and life-science real-estate finance experience from Ventas, preceded by investment banking at UBS and consulting at IBM.
Current title
Executive Vice President & Chief Financial Officer
since November 2022
Experience
no career length stated
Companies before
VentasUBSIBM
Education
University of MichiganBachelor of Engineering
University of Chicago Booth School of BusinessMBA
Other boards
none sourced
Known for
CFOVentascapital marketsUBSIBM

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
He holds a Bachelor of Engineering degree from the University of Michigan and a Master of Business Administration degree from the University of Chicago Booth School of Business.
value seen: University of Michigan — Bachelor of Engineering; University of Chicago Booth School of Business — MBA
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
## Ankit Patel
value seen: Ankit Patel
https://www.biomedrealty.com/company/leadership

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Prior to joining Ventas in 2009, Mr. Patel began his career in investment banking at UBS and management consulting at IBM.
value seen: Ventas; UBS; IBM
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & Chief Financial Officer
value seen: CFO
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Ankit Patel became Chief Financial Officer in November 2022.
value seen: November 2022
https://www.biomedrealty.com/company/leadership

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Ankit Patel became Chief Financial Officer in November 2022. At Ventas, he was the Senior Vice President of Corporate Finance & Capital Markets, where he led corporate finance, strategic planning, and capital markets.
value seen: Ankit Patel leads BioMed Realty’s financial reporting, accounting, planning, tax, treasury, capital markets, IT and asset-management functions. He brings healthcare and life-science real-estate finance experience from Ventas, preceded by investment banking at UBS and consulting at IBM.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Prior to joining Ventas in 2009, Mr. Patel began his career in investment banking at UBS and management consulting at IBM.
value seen: CFO; Ventas; capital markets; UBS; IBM; MBA
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & Chief Financial Officer
value seen: Executive Vice President & Chief Financial Officer
https://www.biomedrealty.com/company/leadership
ML
Marie Lewis
Marie Lewis leads BioMed Realty’s legal, integration, communications and corporate-marketing functions, and has been involved in major leasing, development, acquisition, disposition and financing transactions. Before BioMed, she was real-estate managing attorney at Sempra Energy and an associate at Gibson, Dunn & Crutcher.
Current title
Executive Vice President & General Counsel
Experience
no career length stated
Companies before
Sempra EnergyGibson, Dunn & Crutcher LLP
Education
Loyola Law Schoollaw degree
Other boards
Board of the Big Brothers Big Sisters San Diego Chapter
Known for
General CounsellegalintegrationcommunicationsSempra Energy
https://linkedin.com/in/marie-lewis-exec
since effective October 1, 2023

Sources: education

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
She graduated cum laude from Loyola Law School and clerked for Judge William J. Rea in the Central District of California.
value seen: Loyola Law School — law degree
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: full name

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
## Marie Lewis
value seen: Marie Lewis
https://www.biomedrealty.com/company/leadership

Sources: linkedin page

SOCIAL2026-09-09

Marie Lewis

The Registry · carried by linkedin.com
Executive Vice President and General Counsel - BioMed Realty (Current)
value seen: https://linkedin.com/in/marie-lewis-exec
https://linkedin.com/in/marie-lewis-exec

Sources: other boards

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
She is also on the board of the Big Brothers Big Sisters San Diego Chapter.
value seen: Board of the Big Brothers Big Sisters San Diego Chapter
https://www.biomedrealty.com/company/leadership

Sources: previous companies

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before BioMed, Ms. Lewis was Managing Attorney, Real Estate, at Sempra Energy and an associate at Gibson, Dunn & Crutcher LLP.
value seen: Sempra Energy; Gibson, Dunn & Crutcher LLP
held out of the figures · the quote does not carry this value
https://www.biomedrealty.com/company/leadership

Sources: role type

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & General Counsel
value seen: DEPARTMENT_HEAD
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: since

COMPANY2023-10-02

BioMed Realty Appoints Marie Lewis as Executive Vice ...

BioMed Realty
Ms. Lewis was appointed Executive Vice President and General Counsel effective October 1, 2023.
value seen: effective October 1, 2023
https://www.biomedrealty.com/biomed-realty-appoints-marie-lewis-as-executive-vice-president-and-general-counsel

Sources: summary

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Marie Lewis is Executive Vice President and General Counsel, leading the Company’s Legal, Integration, Communications and corporate Marketing functions. Since joining in 2013 as Managing Attorney, she has played a significant role in numerous leasing, development, acquisition, disposition and financing transactions.
value seen: Marie Lewis leads BioMed Realty’s legal, integration, communications and corporate-marketing functions, and has been involved in major leasing, development, acquisition, disposition and financing transactions. Before BioMed, she was real-estate managing attorney at Sempra Energy and an associate at Gibson, Dunn & Crutcher.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: tags

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
Before BioMed, Ms. Lewis was Managing Attorney, Real Estate, at Sempra Energy and an associate at Gibson, Dunn & Crutcher LLP.
value seen: General Counsel; legal; integration; communications; Sempra Energy
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.biomedrealty.com/company/leadership

Sources: title

COMPANY2025-07-28

Leadership - BioMed Realty

BioMed Realty
#### Executive Vice President & General Counsel
value seen: Executive Vice President & General Counsel
https://www.biomedrealty.com/company/leadership

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

1 evidenced cases

Subsequently completed; historical exception · Last checked: 2026-10-11

Original delivery commitment: Q2 2024. Source publication dates and resolution history are shown with the evidence below.

OVERDUE · Resolved historical case · The project experienced a years-long delay brought on by the COVID-19 pandemic.

OVERDUE · Resolved historical case · The project experienced a years-long delay associated with an ownership change.

Evidence for delay_causes
2025-05-29
coloradobiz.com
The project overcame a years-long delay brought on by the COVID-19 pandemic and an ownership change.
value seen: FORCE_MAJEURE
value paraphrased from this source
https://coloradobiz.com/5505-central/
Evidence for delay_causes
2025-05-29
coloradobiz.com
The project overcame a years-long delay brought on by the COVID-19 pandemic and an ownership change.
value seen: OTHER
value paraphrased from this source
https://coloradobiz.com/5505-central/

Completed projects

10 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
Emery Yards Phase 1Emeryville, United States
office, industrial, masterplan—7271,000 sq ft——2021April 5, 2021Oct 2023 – Dec 2023Feb 2025+15.0 mo
(+14.0 to +16.0)
estimatedcompleted
One GrantaCambridge, United Kingdom
Granta Park
office, other——103,000 sq ftGBP 35m
other
—2023mid-2023Jul 2024 – Sep 2024Sep 2024+1.0 mo
(0.0 to +2.0)
sourcedcompleted
5505 Central AvenueBoulder, United States
Flatiron Office Park
office, other—two-story63,700 sq ft——2022September 2022May 2024 – Aug 2024Aug 2024+1.5 mo
(0.0 to +3.0)
sourcedcompleted
Assembly Innovation Park Phase 1Somerville, United States
Assembly Square
office, industrial—12498,000 sq ftUSD 514m
construction loan
—2022January 2022Apr 2024 – Jun 2024Mar 2024 – May 2024−1.0 mo
(−3.0 to +1.0)
sourcedcompleted
Babraham B960Cambridge, United Kingdom
office, other——34,000 sq ftGBP 20.6m
contract value
—2022October 3, 2022Feb 2024Feb 20240.0 mo
(0.0 to 0.0)
sourcedcompleted
Dexter YardSeattle, United States
South Lake Union
office, industrial, retail, mixed use—15 floors522,760 sq ft————Sep 2020 – Dec 2020Jan 2022 – Dec 2022+20.0 mo
(+13.0 to +27.0)
sourcedcompleted
Gateway of Pacific Phase IISouth San Francisco, United States
East Side
office, other—nine-story441,000 sq ft——2019March 20, 2019Oct 2020 – Dec 2020Jan 2022 – Dec 2022+19.5 mo
(+13.0 to +26.0)
sourcedcompleted
Gateway of Pacific Phase IIISouth San Francisco, United States
East Side
office, other—eleven floors350,000 sq ft——20132013Jan 2021 – Mar 2021Jan 2022 – Dec 2022+16.5 mo
(+10.0 to +23.0)
sourcedcompleted
APEXSan Diego, United States
University Towne Center
office, industrial—4204,000 sq ft——2019October 30, 2019Jan 2021 – Dec 2021Jan 2021 – Dec 20210.0 mo
(−11.0 to +11.0)
sourcedcompleted
Center for Novel TherapeuticsLa Jolla, United States
UC San Diego Science Research Park
office, other——137,500 sq ftUSD 92m
investment announced
—2019September 6, 2019Jan 2019 – Apr 2019Sep 2019+6.5 mo
(+5.0 to +8.0)
sourcedcompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

7 found
PROJECT AWARD Winner 2026
The Outstanding Building of the Year (TOBY) Award — Life Science Building · Gateway of Pacific
Gateway of Pacific in South San Francisco won the 2026 international TOBY Award in the Life Science Building category; BOMA identifies BioMed Realty as both manager and owner.
RANKING Ranked 2025 results, reported December 23, 2025
GRESB Real Estate Assessment — first place in the Development Benchmark, Technology/Science/Non-listed/Core, Americas
The Blackstone Core+ Life Sciences Real Estate strategy, which includes BioMed Realty, ranked first in the specified 2025 GRESB Development Benchmark for the second consecutive year and received a 4-Star rating in both Standing Assets and Development Assets.
COMPANY AWARD May 14, 2025
Fitwel Champion Company
Fitwel recognized BioMed Realty as a Fitwel Champion Company for leadership in promoting health and wellness through the built environment across its portfolio.
RANKING Ranked 2024 results, reported October 30, 2024
GRESB Real Estate Assessment — Real Estate Sector Leader for Technology/Science and first in GRESB peer groups
The Blackstone Core+ Life Sciences Real Estate strategy, described as including BioMed Realty, was recognized as the Technology/Science Real Estate Sector Leader and ranked first in the relevant GRESB peer groups, with 4-Star ratings for Standing Investment and Development.
RANKING Ranked 2023 results, reported October 25, 2023
GRESB Real Estate Assessment — 5-Star rating and #1 ranking in Technology/Science/Americas
BioMed Realty reported that its portfolio received a 5-Star GRESB rating for Standing Investments, a 4-Star Development rating, and a #1 ranking within Technology/Science/Americas.
Global Real Estate Sustainability Benchmark (GRESB) · https://www.biomedrealty.com/wp-content/uploads/2025/10/GRESB2023-press.pdf
SUSTAINABILITY Certified February 2021
LEED Platinum certification · Gateway of Pacific Phase 1
BioMed Realty reported that Gateway of Pacific Phase 1 obtained LEED Platinum certification in February 2021.
SUSTAINABILITY Certified November 2021
BREEAM Excellent rating · Portway Building, Granta Park
BioMed Realty reported that the redeveloped Portway Building at Granta Park received a BREEAM Excellent rating in November 2021.

Risks

Risk flags

6 found
DELIVERY DELAY Reported September 17, 2024; the article described the site as undeveloped and the opening as pushed to 2025.
Towne Centre View, a BioMed Realty project in San Diego, remained undeveloped when reported in September 2024, with its opening date pushed back to 2025 and the precise timeline described as unclear; BioMed said it was still discussing prospective tenants.
SAFETY / LABOUR Liens reported as filed in 2020; source published September 16, 2020 and updated July 30, 2021.
At BioMed Realty’s Gateway of Pacific project, four subcontractors filed mechanics liens alleging unpaid construction work totaling $11,452,002.50; one subcontractor also alleged non-payment, withheld funds and project delays by the general contractor, Turner Construction. The source does not establish that BioMed itself owed the subcontractors, and it records a lien-release bond for one claim.
LEGAL Complaint filed September 24, 2025; reported September 30, 2025.
BioMed Realty sued SmartLabs alleging breach of contract and approximately $2.7 million in unpaid rent and fees at a Cambridge property; the report said the complaint was filed September 24, 2025, and that SmartLabs had not yet responded, so the allegations were unresolved as of publication.
LEGAL Filed September 23, 2020; case page last updated February 7, 2022.
Annette Matthies filed a contract lawsuit naming BioMed Realty Holdings, Inc., BioMed Realty, L.P. and related BioMed entities in San Diego County Superior Court; the court record displayed the case as “Other Pending,” with later demurrer, summary-judgment and trial-related docket entries, and no resolution established by the retrieved record.
DELIVERY DELAY September 2, 2026 notice; earlier 2025 opening commitment reported September 17, 2024; research position as of October 11, 2026
Towne Centre View in San Diego, owned/applicant-linked to BioMed Realty through BRE-BMR Towne Centre Science Park LLC, remained undeveloped after its opening was reportedly pushed to 2025; a September 2026 City notice records BioMed’s project seeking an extension of time for its development permits, so completion was not documented as of October 11, 2026.
PROJECT CANCELLED October 2013 suspension; April 24, 2014 termination; court decision August 29, 2016
The San Diego regenerative-medicine campus planned by Shire Regenerative Medicine/Advanced BioHealing with BioMed Realty as its real-estate partner was suspended in October 2013 and terminated by Shire on April 24, 2014 before completion; the court record identifies the project as a two-building campus with a December 2014 target completion date, and does not attribute the termination to BioMed Realty.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 11, 2026 this month
Profile last researchedOctober 11, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.