Domiki Kritis S.A. — delivery record

Artificial Intelligence
Builders Company

Developers/Domiki Kritis S.A.

Domiki Kritis S.A.Heraklion, Greece · founded 24 March 1985 · 1 active markets

PUBLIC LISTED

www.domik.gr

Domiki Kritis builds public and private infrastructure, buildings, ports, roads, hydraulic systems, industrial facilities, renewable-energy projects, environmental works and real-estate developments across Greece. It serves public authorities, private clients, communities and institutional partners through contracting, construction and property-related activities and services.

Years in business

founded 24 March 1985

LinkedIn headcount

13 people

employees, as shown on LinkedIn · 2026 · size band 51–200

Projects last researched October 15, 2026

Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name: Domiki Kritis Anonymous Technical, Commercial, Hotel, Industrial Company¹
Headquarters: Koronaiou 14¹, Heraklion¹, Greece
Founded: 24 March 1985¹
Entity type: PUBLIC LISTED¹
Business model: contracting¹, commercial¹, masterplan¹, other¹
Markets: 1 market listed
What they build: no project types recorded

Full dossier in About →

Delivery record

0 date-assessed of 0 projects

Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.

Completed projects assessed

within the rolling ten-year window

Median delay

—

the middle of no scored projects

Average delay

—

the same projects, pulled by the worst

Average time to deliver

—

no delivered projects with a dated start — needs 3

Worst slip

—

early or less than 6 months late

6 to 12 months late

yellow rows below

Over 12 months late

red rows below

Against other developers

Not enough info yet.

Projects and timelines in Track Record →

Awards & recognition

COMPANY AWARD Ranked 2013 (reported February 6, 2014)
ΧΡΗΜΑ – Γ. Ουζούνης 2013: High Growth Rates Award
Domiki Kritis was ranked second in the 2013 High Growth Rates Award category; the award recognized companies contributing to the development of the stock-market institution and the Greek economy.
Ethos Media / ΧΡΗΜΑ · https://www.in.gr/2014/02/06/economy/agores-epixeiriseis/oi-etaireies-poy-ksexwrisan-sta-epixeirimat…
SAFETY / QUALITY Certified
ELOT EN ISO 45001:2018 Occupational Health and Safety Management certification
The developer reports that it is certified to ELOT EN ISO 45001:2018 for its occupational health and safety management system.
Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system
SAFETY / QUALITY Certified
ELOT EN ISO 9001:2015 Quality Management certification
The developer reports that it is certified to ELOT EN ISO 9001:2015 for its quality management system.
Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system
2 more in Awards

All awards →

Risks & source coverage

DELIVERY DELAY Reported in the 2024 annual report approved April 30, 2025; reaffirmed for the first half of 2025 in the report dated September 29, 2025. The company’s 2024 annual report said construction-project execution had slowed because financing of public works was delayed; the same report attributed lower sales and weaker results partly to that slower execution. This is a company-level disclosure of execution delay, not evidence that a particular project was abandoned, and the later 2025 interim report still said revenue was lower because construction execution had slowed.
athens.euronext.com · https://athens.euronext.com/el/ixbrlv/1233936
LEGAL Reported October 11, 2017. A third party sued Domiki Kritis and its then-chairman for €4,498,671.31, alleging tort liability in connection with an earlier share sale; the company said the case was pending and that it could not assess the outcome, so this is an unresolved reported claim rather than a finding of liability.
euro2day.gr · https://www.euro2day.gr/chameleon/article-blog-chameleon/1571209/h-domikh-krhths-kai-h-agogh-ton-45-…
REGULATORY Regulatory decision reported October 2, 2007. The Hellenic Capital Market Commission imposed fines in connection with trading that it found involved arranged transactions intended to artificially shape the price and trading activity of Domiki Kritis shares; the fines included €30,000 against the company’s then-chairman and fines against the intermediaries involved. This is a historic regulatory matter, outside the rolling ten-year window, included because it is a material matter involving the company’s listed shares; no current status or later resolution was established from the retrieved source.
services.naftemporiki.gr · https://services.naftemporiki.gr/finance/story/161060/kampanes-250000-euro-apo-tin-epitropi-kefalaia…
1 more in Risk & Sources

Record status: active
Company sources: 117 source entries across 116 fields
Projects tracked: 0 · 0 completed in assessment

All flags and sources →

Track Record

Delivery record

0 date-assessed of 0 projects

Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects assessed

within the rolling ten-year window

Median delay

—

the middle of no scored projects

Average delay

—

the same projects, pulled by the worst

Average time to deliver

—

no delivered projects with a dated start — needs 3

Worst slip

—

early or less than 6 months late

6 to 12 months late

yellow rows below

Over 12 months late

red rows below

Against other developers

Not enough info yet.

Construction start to handover

0 of 0 projects dated · 0 places

Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.

Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled

No dated projects to plot.

Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures.

About

Company dossier

Legal name

Domiki Kritis Anonymous Technical, Commercial, Hotel, Industrial Company

Headquarters

Koronaiou 14, Heraklion, Greece

71202

Founded

24 March 1985

Greece

Entity type

PUBLIC LISTED

Revenue

EUR 15.68 million annual group sales

2024

Business model

contracting, commercial, masterplan, other

Offices

head office and 1 other

Marousi

Sources: office cities

COMPANYdate not shown in source

ΙΣΤΟΡΙΚΟ

Domiki Kritis · carried by domik.gr

Επίσης το 2023 τα γραφεία στην Αθήνα στεγάζονται επί της Οδού Αποστόλου Παύλου 4 στο Μαρούσι Αττικής.

value seen: Οδός Αποστόλου Παύλου 4, ΤΚ 151 23, Μαρούσι Αττικής

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://domik.gr/index.php/el/etairia/istoriko

Partners

2 partners

Mirum Hellas

partner

Domiki Kritis signed an Early Contractor Involvement agreement and then a construction contract for the first Elounda Hills residential phase.

AKTOR S.A.

contractor

AKTOR and Domiki Kritis signed an Early Contractor Involvement agreement with Mirum for Elounda Hills, bringing both contractors into planning and delivery.

Sources: name

PRESS2026-09-11

Δομική Κρήτης: Σύμβαση €6,44 εκατ. με τη Mirum για το project στην Ελούντα

Capital.gr

Η Δομική Κρήτης ανακοίνωσε την υπογραφή νέας σύμβασης με τη Mirum Hellas για το έργο της επένδυσης στην Ελούντα Λασιθίου.

value seen: Mirum Hellas

https://www.capital.gr/epixeiriseis/4016193/domiki-kritis-sumbasi-644-ekat-me-ti-mirum-gia-to-project-stin-elounta/

Sources: partner type

PRESS2026-09-11

Δομική Κρήτης: Σύμβαση €6,44 εκατ. με τη Mirum για το project στην Ελούντα

Capital.gr

Η Δομική Κρήτης ανακοίνωσε την υπογραφή νέας σύμβασης με τη Mirum Hellas

value seen: κατασκευαστικής σύμβασης

no listed category matches this wording, so it is shown as the source wrote it

held out of the figures · no listed category matches this wording

value paraphrased from this source

https://www.capital.gr/epixeiriseis/4016193/domiki-kritis-sumbasi-644-ekat-me-ti-mirum-gia-to-project-stin-elounta/

Sources: summary

PRESS2026-09-11

Δομική Κρήτης: Σύμβαση €6,44 εκατ. με τη Mirum για το project στην Ελούντα

Capital.gr

Η σύμβαση αφορά εκσκαφές, κατασκευή σκελετού από σκυρόδεμα και ενσωματούμενα ηλεκτρομηχανολογικά (Η/Μ) για 24 διαμερίσματα (Marina Branded Apartments) και δύο βίλες (Waterfront Branded Villas)

value seen: 24 διαμερίσματα (Marina Branded Apartments) και δύο βίλες (Waterfront Branded Villas)

value paraphrased from this source

https://www.capital.gr/epixeiriseis/4016193/domiki-kritis-sumbasi-644-ekat-me-ti-mirum-gia-to-project-stin-elounta/

Sources: name

PRESS2026-04-28

Περνάει σε φάση υλοποίησης το Elounda Hills - «Έπεσαν» οι υπογραφές με AKTOR και Δομική Κρήτης - CNN.gr

CNN.gr

AKTOR και ΔΟΜΙΚΗ ΚΡΗΤΗΣ υπέγραψαν σύμβαση Early Contractor Involvement (ECI) με τον Όμιλο Mirum για το έργο Elounda Hills

value seen: AKTOR και ΔΟΜΙΚΗ ΚΡΗΤΗΣ

https://www.cnn.gr/oikonomia/epixeiriseis/story/530935/pernaei-se-fasi-ylopoiisis-to-elounda-hills-epesan-oi-ypografes-me-aktor-kai-domiki-kritis

Sources: partner type

PRESS2026-04-28

Περνάει σε φάση υλοποίησης το Elounda Hills - «Έπεσαν» οι υπογραφές με AKTOR και Δομική Κρήτης - CNN.gr

CNN.gr

AKTOR και ΔΟΜΙΚΗ ΚΡΗΤΗΣ υπέγραψαν σύμβαση Early Contractor Involvement (ECI) με τον Όμιλο Mirum για το έργο Elounda Hills

value seen: σύμβαση Early Contractor Involvement (ECI)

no listed category matches this wording, so it is shown as the source wrote it

held out of the figures · no listed category matches this wording

value paraphrased from this source

https://www.cnn.gr/oikonomia/epixeiriseis/story/530935/pernaei-se-fasi-ylopoiisis-to-elounda-hills-epesan-oi-ypografes-me-aktor-kai-domiki-kritis

Sources: summary

PRESS2026-04-28

Περνάει σε φάση υλοποίησης το Elounda Hills - «Έπεσαν» οι υπογραφές με AKTOR και Δομική Κρήτης - CNN.gr

CNN.gr

Σύμφωνα με τη σχετική ανακοίνωση, το μοντέλο ECI εντάσσει τους κατασκευαστές πριν την οριστικοποίηση των συμβατικών τιμών, επιτρέποντας τη διασφάλιση χρονοδιαγραμμάτων και τη βελτιστοποίηση κόστους.

value seen: το μοντέλο ECI εντάσσει τους κατασκευαστές πριν την οριστικοποίηση των συμβατικών τιμών

value paraphrased from this source

https://www.cnn.gr/oikonomia/epixeiriseis/story/530935/pernaei-se-fasi-ylopoiisis-to-elounda-hills-epesan-oi-ypografes-me-aktor-kai-domiki-kritis

Registrations & licences

COMPANY NUMBER

077089627000
General Commercial Registry (G.E.MI.) · Greece · active operating company

Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries

Greece

active 0 projects tracked

What they build

no project types recorded

A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found

Georgios Synatsakis

Founder of Domiki Kritis and its current CEO, with general-management responsibility. The company identifies him as a surveying engineer of the National Technical University of Athens; independent reporting also describes him as the founder and a long-standing construction-sector executive.

Current title

Founder; Chief Executive Officer; Executive Board Member

since 8 September 2023

Experience

no career length stated

Companies before

none sourced

Education

National Technical University of AthensSurveying engineering

Other boards

none sourced

Known for

FounderCEOSurveying engineerConstruction sector

Sources: education

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Συνατσάκης Μ. Γεώργιος - Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος- Εκτελεστικό Μέλος του Δ.Σ. και Διευθύνων Σύμβουλος

value seen: Τοπογράφος Μηχανικός ΕΜΠ

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: Georgios Synatsakis

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: FOUNDER

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: since

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Η εταιρεία ΔΟΜΙΚΗ ΚΡΗΤΗΣ Α.Ε. διοικείται από 7 μελές Διοικητικό Συμβούλιο που συγκροτήθηκε σε σώμα στις 8 Σεπτεμβρίου 2023 με πενταετή θητεία.

value seen: 8 September 2023

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: Founder of Domiki Kritis and its current CEO, with general-management responsibility. The company identifies him as a surveying engineer of the National Technical University of Athens; independent reporting also describes him as the founder and a long-standing construction-sector executive.

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: Founder

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: CEO

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: Surveying engineer

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος

value seen: Construction sector

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: Ιδρυτής της εταιρείας, Τοπογράφος Μηχανικός ΕΜΠ, Διευθύνων Σύμβουλος- Εκτελεστικό Μέλος του Δ.Σ. και Διευθύνων Σύμβουλος

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Dimitrios Koutras

Executive chairman since the 2023 board reorganisation, with a long construction track record. Independent reporting describes prior leadership at AKTOR and a vice-chair role at Intrakat; those are historical roles, not current Domiki titles.

Current title

Chairman; Executive Board Member

since 8 September 2023

Experience

no career length stated

Companies before

AKTORIntrakat

Education

National Technical University of AthensMining engineering

Other boards

none sourced

Known for

ChairmanConstruction executiveex-AKTORex-Intrakat

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Μεταλλειολόγος διπλωματούχος Μηχανικός ΕΜΠ- Εκτελεστικό Μέλος του Δ.Σ. και Πρόεδρος του Διοικητικού Συμβουλίου

value seen: Dimitrios Koutras

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: previous companies

PRESS2023-06-26

Δ. Κούτρας: Μπαίνει στη Δομική Κρήτης - Αποχωρεί από την Intrakat

Michanikos Online

Στη Δομική Κρήτης μπαίνει ο Δημήτριος Κούτρας, πρώην στέλεχος της ΑΚΤΩΡ και πρώην Αντιπρόεδρος της Intrakat

value seen: ΑΚΤΩΡ; Intrakat

https://www.michanikos-online.gr/%ce%b4-%ce%ba%ce%bf%cf%8d%cf%84%cf%81%ce%b1%cf%82-%ce%bc%cf%80%ce%b1%ce%af%ce%bd%ce%b5%ce%b9-%cf%83%cf%84%ce%b7-%ce%b4%ce%bf%ce%bc%ce%b9%ce%ba%ce%ae-%ce%ba%cf%81%ce%ae%cf%84%CE%B7%CF%82-%ce%b1/

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: CHAIR

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: since

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: 8 September 2023

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by michanikos-online.gr

Ο κ. Κούτρας εισέρχεται στη Δομική Κρήτης

value seen: Executive chairman since the 2023 board reorganisation, with a long construction track record. Independent reporting describes prior leadership at AKTOR and a vice-chair role at Intrakat; those are historical roles, not current Domiki titles.

held out of the figures · the quote does not carry this value

value paraphrased from this source

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: Chairman

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: Construction executive

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: ex-AKTOR

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: ex-Intrakat

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Κουτράς Αθ. Δημήτριος - Μεταλλειολόγος διπλωματούχος Μηχανικός ΕΜΠ- Εκτελεστικό Μέλος του Δ.Σ. και Πρόεδρος του Διοικητικού Συμβουλίου

value seen: Μεταλλειολόγος διπλωματούχος Μηχανικός ΕΜΠ- Εκτελεστικό Μέλος του Δ.Σ. και Πρόεδρος του Διοικητικού Συμβουλίου

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Alkyoni Synatsaki

A mineral-resources engineer who has worked at Domiki Kritis in quantity-surveying and administrative services. She brings technical and operating familiarity to the board.

Current title

Vice Chair; Non-Executive Board Member

since 8 September 2023

Experience

no career length stated

Companies before

none sourced

Education

Technical University of CreteMineral-resources engineering

Other boards

none sourced

Known for

Vice chairMineral-resources engineerPolytechnic of CreteDomiki Kritis experience

Sources: education

COMPANYdate not shown in source

Η συμμετοχή της κα. Συνατσάκη με τις γνώσεις της, συμπίπτουν με τον τομέα δραστηριότητας της εταιρείας και την καθιστά ικανό ως μέλος του Δ.Σ.

Domiki Kritis S.A. · carried by domik.gr

Είναι διπλωματούχος Μηχανικός Ορυκτών Πόρων με σπουδές στον τομέα της Μεταλλευτικής Τεχνολογίας του Πολυτεχνείου Κρήτης.

value seen: Πολυτεχνείο Κρήτης

held out of the figures · the quote does not carry this value

https://www.domik.gr/images/pdf/genikes-sineleuseis/08%2009%202023/%CE%92%CE%99%CE%9F%CE%93%CE%A1%CE%91%CE%A6%CE%99%CE%9A%CE%91/%CE%91%CE%BB%CE%BA%CF%85%CF%8C%CE%BD%CE%B7%20%CE%A3%CF%85%CE%BD%CE%B1%CF%84%CF%83%CE%AC%CE%BA%CE%B7.pdf

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Alkyoni Synatsaki

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: previous companies

COMPANYdate not shown in source

Domiki Kritis S.A. · carried by domik.gr

Ολοκληρώνοντας τις σπουδές της έχει εργαστεί στην εταιρεία ΔΟΜΙΚΗ ΚΡΗΤΗΣ Α.Ε. στον τομέα των επιμετρήσεων καθώς και διοικητικών υπηρεσιών.

value seen: ΔΟΜΙΚΗ ΚΡΗΤΗΣ Α.Ε.

held out of the figures · the quote does not carry this value

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: BOARD_MEMBER

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: since

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: 8 September 2023

value paraphrased from this source

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: A mineral-resources engineer who has worked at Domiki Kritis in quantity-surveying and administrative services. She brings technical and operating familiarity to the board.

held out of the figures · the quote does not carry this value

value paraphrased from this source

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Vice chair

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Mineral-resources engineer

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Polytechnic of Crete

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Domiki Kritis experience

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Συνατσάκη Γ. Αλκυόνη -Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

value seen: Συνατσάκη Γ. Αλκυόνη -Διπλωματούχος Μηχανικός Ορυκτών Πόρων, Μη Εκτελεστικό Μέλος του Δ.Σ. και Αντιπρόεδρος

held out of the figures · the quote does not carry this value

Konstantinos Makrydakis

A civil engineer with transport and infrastructure training and early experience at major Greek contractors and an advisory firm. His documented background is project and infrastructure oriented, but the retrieved material does not establish an executive operating role at Domiki Kritis.

Current title

Non-Executive Board Member

since 8 September 2023

Experience

no career length stated

Companies before

AKTORINTRAKATSOL Crowe Consulting

Education

National Technical University of AthensCivil engineering

Other boards

none sourced

Known for

Civil engineerInfrastructureex-AKTORex-INTRAKAT

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Konstantinos Makrydakis

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: previous companies

COMPANYdate not shown in source

Κωνσταντίνος Μακρυδάκης- Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Ολοκληρώνοντας τις σπουδές του έχει εργαστεί στις εταιρείες ΑΚΤΩΡ Α.Ε, ΙΝΤΡΑΚΑΤ Α.Ε. και ΣΟΛ CROWE Συμβουλευτική.

value seen: ΑΚΤΩΡ Α.Ε, ΙΝΤΡΑΚΑΤ Α.Ε. και ΣΟΛ CROWE Συμβουλευτική

https://www.domik.gr/images/pdf/genikes-sineleuseis/08%2009%202023/%CE%92%CE%99%CE%9F%CE%93%CE%A1%CE%91%CE%A6%CE%99%CE%9A%CE%91/%CE%9A%CF%89%CE%BD%CF%83%CF%84%CE%AF%CE%BD%CE%BF%CF%82%20%CE%9C%CE%B1%CE%BA%CF%81%CF%85%CE%B4%CE%AC%CE%BA%CE%B7%CF%82.pdf

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: BOARD_MEMBER

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: since

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: 8 September 2023

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: A civil engineer with transport and infrastructure training and early experience at major Greek contractors and an advisory firm. His documented background is project and infrastructure oriented, but the retrieved material does not establish an executive operating role at Domiki Kritis.

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/images/pdf/genikes-sineleuseis/08%2009%202023/%CE%92%CE%99%CE%9F%CE%93%CE%A1%CE%91%CE%A6%CE%99%CE%9A%CE%91/%CE%9A%CF%89%CE%BD%CF%83%CF%84%CE%AC%CE%BD%CF%84%CE%B9%CE%BD%CE%BF%CF%82%20%CE%9C%CE%B1%CE%BA%CF%81%CF%85%CE%B4%CE%AC%CE%BA%CE%B7%CF%82.pdf

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Civil engineer

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Infrastructure

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: ex-AKTOR

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: ex-INTRAKAT

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Μακρυδάκης Ανδ. Κωνσταντίνος - Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Διπλωματούχος Πολιτικός Μηχανικός .-Μη Εκτελεστικό Μέλος του Δ.Σ.

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Antonios Adamis

A finance professional who joined the Domiki Kritis construction group in February 2010 and works across investor relations, risk/compliance and group operating areas. He is also documented as chairman of Domiki Viomichaniki and DIA, and vice-chair of Aioliko Roumani.

Current title

Non-Executive Board Member; Head of Shareholders & Corporate Announcements

since 8 September 2023

Experience

no career length stated

Companies before

Piraeus Bank

Education

University of EssexFinance; postgraduate degrees in Finance & Business Economics and Accounting & Auditing

Other boards

Chairman, Domiki Viomichaniki A.E.Chairman, DIA A.E.Vice-chair, Aioliko Roumani A.E.

Known for

FinanceSince February 2010Investor relationsRisk & complianceSubsidiary boards

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Antonios Adamis

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: other boards

COMPANYdate not shown in source

ΑΝΤΩΝΗΣ ΑΔΑΜΗΣ -Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Τέλος είναι Πρόεδρος Δ.Σ. των εταιρειών Δομική Βιομηχανική Α.Ε., της ΔΙΑ Α.Ε. που δραστηριοποιείται στην ανάπτυξη Real Estate, Αντιπρόεδρος της Αιολικό Ρουμάνι ΑΕ με αντικείμενο την παραγωγή ηλεκτρικής ενεργείας από ανανεώσιμες πηγές ενέργειας

value seen: Πρόεδρος Δ.Σ. των εταιρειών Δομική Βιομηχανική Α.Ε., της ΔΙΑ Α.Ε.; Αντιπρόεδρος της Αιολικό Ρουμάνι ΑΕ

held out of the figures · the quote does not carry this value

https://www.domik.gr/images/pdf/genikes-sineleuseis/08%2009%202023/%CE%92%CE%99%CE%9F%CE%93%CE%A1%CE%91%CE%A6%CE%99%CE%9A%CE%91/%CE%91%CE%9D%CE%A4%CE%A9%CE%9D%CE%97%CE%A3%20%CE%91%CE%94%CE%91%CE%9C%CE%97%CE%A3.pdf

Sources: previous companies

COMPANYdate not shown in source

ΑΝΤΩΝΗΣ ΑΔΑΜΗΣ -Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Ολοκληρώνοντας τις σπουδές του εργάστηκε σε διάφορες εταιρείες του Χρηματοοικονομικού και Χρηματοπιστωτικού Κλάδου μεταξύ άλλων στην Διεύθυνση Μεγάλων Επιχειρήσεων και Project Finance της Τράπεζα Πειραιώς.

value seen: Τράπεζα Πειραιώς

held out of the figures · the quote does not carry this value

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: BOARD_MEMBER

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: since

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

value seen: 8 September 2023

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

COMPANYdate not shown in source

ΑΝΤΩΝΗΣ ΑΔΑΜΗΣ -Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Από το Φεβρουάριο του 2010 έχει ενταχθεί στον κατασκευαστικό Όμιλο Δομική Κρήτης

value seen: Από το Φεβρουάριο του 2010

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Από το Φεβρουάριο του 2010 έχει ενταχθεί στον κατασκευαστικό Όμιλο Δομική Κρήτης

value seen: A finance professional who joined the Domiki Kritis construction group in February 2010 and works across investor relations, risk/compliance and group operating areas. He is also documented as chairman of Domiki Viomichaniki and DIA, and vice-chair of Aioliko Roumani.

value paraphrased from this source

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Finance

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Since February 2010

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Investor relations

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Risk & compliance

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Subsidiary boards

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Αδάμης Οδ. Αντώνιος - Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Διπλωματούχος Οικονομολόγος-Μη Εκτελεστικό Μέλος του Δ.Σ.

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Eleni Zenakou

An economist and public-sector audit specialist appointed to the board after replacing Lydia Papadopoulou as an independent member. Her background includes the Ministry of the Presidency, the Court of Audit and audit-committee work at listed companies.

Current title

Independent Non-Executive Board Member; Chair of the Audit Committee

Experience

no career length stated

Companies before

Ministry of the PresidencyCourt of Audit

Education

University of PiraeusEconomics, Business Organisation and Administration

Other boards

Former audit-committee roles at ADMIE Holdings, Lanakam and Yalco (historical service)

Known for

EconomistAudit committee chairCourt of AuditListed-company governance

Sources: education

COMPANYdate not shown in source

Ελένη Ζενάκου- Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Ελένη Ζενάκου- Σύντομο βιογραφικό σημείωμα Γεννήθηκε στην Αθήνα το 1953 είναι πτυχιούχος Οικονομολόγος του τμήματος Οργάνωσης και Διοίκησης Επιχειρήσεων του Πανεπιστημίου Πειραιώς

value seen: Πανεπιστημίου Πειραιώς

held out of the figures · the quote does not carry this value

https://www.domik.gr/images/pdf/genikes-sineleuseis/2025/%CE%A3%CF%85%CE%BD%CE%BF%CF%80%CF%84%CE%B9%CE%BA%CF%8C%20%CE%92%CE%B9%CE%BF%CE%B3%CF%81%CE%B1%CF%86%CE%B9%CE%BA%CF%8C%20%CE%95%CE%BB%CE%AD%CE%BD%CE%B7%CF%82%20%CE%96%CE%B5%CE%BD%CE%AC%CE%BA%CE%BF%CF%85.pdf

Sources: full name

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Eleni Zenakou

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: other boards

COMPANYdate not shown in source

Ελένη Ζενάκου- Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

σε εταιρείες όπως η ΑΔΜΗΕ ΣΥΜΜΕΤΟΧΩΝ Α.Ε., ΛΑΝΑΚΑΜ Α.Ε. και YALCO Α.Ε.

value seen: ΑΔΜΗΕ ΣΥΜΜΕΤΟΧΩΝ Α.Ε., ΛΑΝΑΚΑΜ Α.Ε. και YALCO Α.Ε.

value paraphrased from this source

Sources: previous companies

COMPANYdate not shown in source

Ελένη Ζενάκου- Σύντομο βιογραφικό σημείωμα

Domiki Kritis S.A. · carried by domik.gr

Υπηρέτησε από το 1991 έως το 2002 στο Υπουργείο Προεδρίας και το Σώμα Επιθεωρητών Δημόσιας Διοίκησης. • Από το 2002 έως το 2020 υπηρέτησε στο Ελεγκτικό Συνέδριο

value seen: Υπουργείο Προεδρίας; Ελεγκτικό Συνέδριο

held out of the figures · the quote does not carry this value

Sources: role type

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: BOARD_MEMBER

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: summary

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Από το 2002 έως το 2020 υπηρέτησε στο Ελεγκτικό Συνέδριο, μεταξύ άλλων ως Επίτροπος στα Υπουργεία Εμπορικής Ναυτιλίας και Περιβάλλοντος & Ενέργειας.

value seen: An economist and public-sector audit specialist appointed to the board after replacing Lydia Papadopoulou as an independent member. Her background includes the Ministry of the Presidency, the Court of Audit and audit-committee work at listed companies.

held out of the figures · the quote does not carry this value

value paraphrased from this source

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Economist

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Audit committee chair

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Court of Audit

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: tags

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Listed-company governance

held out of the figures · the quote does not carry this value

value paraphrased from this source

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Sources: title

COMPANYdate not shown in source

ΔΙΟΙΚΗΤΙΚΟ ΣΥΜΒΟΥΛΙΟ

Domiki Kritis S.A. · carried by domik.gr

Ελένη Ζενάκου- Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

value seen: Ελένη Ζενάκου- Διπλωματούχος Οικονομολόγος-Ανεξάρτητο Μη Εκτελεστικό Μέλος του Δ.Σ.

held out of the figures · the quote does not carry this value

https://www.domik.gr/index.php/el/etairia/dioikitiko-sumvoulio

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

No qualifying completions found in this window.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases

The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

0 projects

Project

Location

Type

Units

Floors

Area

Cost

Payment plan

Launched

Construction start

Original target

Handover

Delay

Confidence

Status

Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

5 found

COMPANY AWARD Ranked 2013 (reported February 6, 2014)
ΧΡΗΜΑ – Γ. Ουζούνης 2013: High Growth Rates Award
Domiki Kritis was ranked second in the 2013 High Growth Rates Award category; the award recognized companies contributing to the development of the stock-market institution and the Greek economy.

Ethos Media / ΧΡΗΜΑ · https://www.in.gr/2014/02/06/economy/agores-epixeiriseis/oi-etaireies-poy-ksexwrisan-sta-epixeirimat…

SAFETY / QUALITY Certified
ELOT EN ISO 45001:2018 Occupational Health and Safety Management certification
The developer reports that it is certified to ELOT EN ISO 45001:2018 for its occupational health and safety management system.

Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system

SAFETY / QUALITY Certified
ELOT EN ISO 9001:2015 Quality Management certification
The developer reports that it is certified to ELOT EN ISO 9001:2015 for its quality management system.

Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system

SUSTAINABILITY Certified
ELOT EN ISO 14001:2015 Environmental Management certification
The developer reports that it is certified to ELOT EN ISO 14001:2015 for its environmental management system.

Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system

SUSTAINABILITY Certified
ELOT EN ISO 50001:2018 Energy Management certification
The developer reports that it is certified to ELOT EN ISO 50001:2018 for its energy management system.

Not stated on the retrieved page · https://www.domik.gr/index.php/el/etairia/quality-system

Risks

Auditor & credit ratings

audited accounts

Auditor

Grant Thornton Greece

Risk flags

4 found

DELIVERY DELAY Reported in the 2024 annual report approved April 30, 2025; reaffirmed for the first half of 2025 in the report dated September 29, 2025.
The company’s 2024 annual report said construction-project execution had slowed because financing of public works was delayed; the same report attributed lower sales and weaker results partly to that slower execution. This is a company-level disclosure of execution delay, not evidence that a particular project was abandoned, and the later 2025 interim report still said revenue was lower because construction execution had slowed.

athens.euronext.com · https://athens.euronext.com/el/ixbrlv/1233936

LEGAL Reported October 11, 2017.
A third party sued Domiki Kritis and its then-chairman for €4,498,671.31, alleging tort liability in connection with an earlier share sale; the company said the case was pending and that it could not assess the outcome, so this is an unresolved reported claim rather than a finding of liability.

euro2day.gr · https://www.euro2day.gr/chameleon/article-blog-chameleon/1571209/h-domikh-krhths-kai-h-agogh-ton-45-…

REGULATORY Regulatory decision reported October 2, 2007.
The Hellenic Capital Market Commission imposed fines in connection with trading that it found involved arranged transactions intended to artificially shape the price and trading activity of Domiki Kritis shares; the fines included €30,000 against the company’s then-chairman and fines against the intermediaries involved. This is a historic regulatory matter, outside the rolling ten-year window, included because it is a material matter involving the company’s listed shares; no current status or later resolution was established from the retrieved source.

services.naftemporiki.gr · https://services.naftemporiki.gr/finance/story/161060/kampanes-250000-euro-apo-tin-epitropi-kefalaia…

DELIVERY DELAY Publication: 24 April 2015; official recorded completion date: 20 October 2018.
The Gournès–Hersonissos section of Crete’s BOAK, awarded to the joint venture Domiki Kritis–EKTER–ERETVO–THEMELI, was contractually due for completion in October 2015 but was reported at only about 15% shortly before that deadline; the completion horizon was subsequently moved to 2017 and the public authority records a project completion date of 20 October 2018, documenting a material delivery delay rather than an unresolved current failure.

oakae.gr · https://oakae.gr/erga-ypodomon/sygkoinoniaka-erga/gournes-chersonisos/

Record status

active

Coverage	active
Tracked since	October 10, 2026
Last checked	October 15, 2026 this month
Profile last researched	October 15, 2026
Claim

Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.

For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.