Artificial Intelligence
Builders Company
Developers/Hudson
H
HudsonNew York, United States · founded 1986 · 1 active markets
PRIVATE

Hudson develops, builds, owns, and manages housing and mixed-use properties across New York City and the wider New York metropolitan area, serving market-rate, affordable, institutional, supportive, transitional, rental, cooperative, condominium, and commercial users through development, preservation, renovation, and partnerships communities.

Years in business
40
founded 1986
LinkedIn headcount
50
employees, as shown on LinkedIn · size band 11–50
Portfolio value
USD 3.6 billion total capital
as the company states it
Units delivered
9,903
as the company states it
Projects last researched October 15, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
The Hudson Companies Inc.1
Headquarters
826 Broadway1, New York1, United States
Founded
19861
Entity type
PRIVATE1
Business model
offplan for sale1, build to sell institutional1, commercial1, mixed use1, masterplan1
Markets
1 market listed
What they build
Residential, for rent (9 of 10) · Retail (6 of 10) · Mixed use (6 of 10)
Full dossier in About →

Delivery record

7 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
0.0 mo
the middle of 7 scored projects
Average delay
+2.8 mo
the same projects, pulled by the worst
Average time to deliver
2.9 yrs
start to completion, over 7 delivered projects
Worst slip
+11.5 mo
The Peninsula Phase I · +6.0 to +17.0
5
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
0
red rows below

Against other developers

7 date-assessed here · 260 developers, 976 date-assessed projects in United States
Median delay
Hudson·260 developers in United States
0.0 mo vs +4.5 mo
this developer 4.5 mo better
The typical project on each side.
Average delay
Hudson·260 developers in United States
+2.8 mo vs +7.4 mo
this developer 4.6 mo better
Both pulled by their worst few.
On time
Hudson·260 developers in United States
71% vs 56%
this developer 15 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Hudson·260 developers in United States
2.9 yrs vs 2.9 yrs
this developer is level
Start to completion, over 7 delivered here and 803 in the market.
Projects and timelines in Track Record →

Resident experience

5 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
6.7/ 10
Weighted judgment across build and operations · from 5 of 5 rated buildings
Little structure evidence (1 of 5 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
5.8/ 10
Fabric, services, waterproofing, envelope · from 1 of 5 rated buildings
Management & living
6.5/ 10
Upkeep, response times, amenities, community · from 2 of 5 rated buildings

Against other developers

5 rated here · 283 developers, 1449 rated buildings in United States
Overall rating
Hudson · 283 other developers in United States
6.7 vs 7.8
this developer 1.1 worse
The weighted verdict on each side. From 5 of 5 rated buildings here and 1449 in the market.
Structure & systems
Hudson · 283 other developers in United States
— vs 6.9
Too few buildings with this score here to compare (1 of 5)
Fabric and engineering only — fixed at handover. From 1 of 5 rated buildings here and 627 in the market.
Management & living
Hudson · 283 other developers in United States
— vs 7.4
Too few buildings with this score here to compare (2 of 5)
Upkeep and response — belongs to whoever runs the building now. From 2 of 5 rated buildings here and 1397 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.
Ratings by building →

Awards & recognition

  • PROJECT AWARD Winner 2023
    Excellence in Market-Rate Housing Development · One Clinton
    One Clinton won the Urban Land Institute award for Excellence in Market-Rate Housing Development; the ULI event page identifies The Hudson Companies’ development team with the winning project.
  • PROJECT AWARD Winner 2023
    Excellence in Exterior, Interior, and Outdoor Space · Castleton Housing
    The Hudson Companies’ awards page reports Castleton Housing as the recipient of the Staten Island Chamber of Commerce award for Excellence in Exterior, Interior, and Outdoor Space.
    Staten Island Chamber of Commerce · https://www.hudsoninc.com/awards-press/awards/
  • SUSTAINABILITY Winner 2021
    Buildings of Excellence · Greenpoint Hospital
    The Hudson Companies’ awards page reports Greenpoint Hospital as a Buildings of Excellence award recipient in NYSERDA’s multifamily-building competition.
    New York State Energy Research and Development Authority (NYSERDA) · https://www.hudsoninc.com/awards-press/awards/
  • 4 more in Awards
All awards →

Risks & source coverage

  • SAFETY / LABOUR Accident reported as September 11, 2018; Supreme Court order October 2, 2024; Appellate Division decision February 5, 2026 A New York Appellate Division opinion affirmed partial summary judgment against the project owner/general contractor on a Labor Law §240(1) claim after a worker was struck by unsecured, leaning 250-pound doorframes; the court dismissed the related third-party claims against the hoist/crane defendants, while Hudson Companies was named as a defendant in the action. The underlying accident occurred at the Athena Housing project, and the decision does not establish that Hudson itself caused the unsafe condition.
  • LEGAL Reported April 6, 2023; complaint filed in April 2023 Four Parkline tenants filed a proposed class-action lawsuit against Hudson affiliate Hudson CBD Flatbush LLC, alleging that rent concessions were used to register higher rents and that concessions were withdrawn at renewal, producing unlawful rent overcharges; the article reported the allegations and a proposed class but no final merits resolution.
  • DELIVERY DELAY Delay reported January 23, 2017; current Hudson project page lists anticipated construction in 2026 and completion in 2028 Gowanus Green, a Hudson-led joint venture project, was reported in 2017 as having missed its repeatedly pushed completion target and lacking a reliable target date because of environmental remediation and approval issues; Hudson’s current project page lists completion as 2028 and construction as anticipated in 2026, which is a future commitment rather than evidence of completion as of October 15, 2026.
  • 1 more in Risk & Sources
Record status
active
Company sources
169 source entries across 166 fields
Projects tracked
10 · 10 completed in assessment
All flags and sources →

Track Record

Delivery record

7 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
0.0 mo
the middle of 7 scored projects
Average delay
+2.8 mo
the same projects, pulled by the worst
Average time to deliver
2.9 yrs
start to completion, over 7 delivered projects
Worst slip
+11.5 mo
The Peninsula Phase I · +6.0 to +17.0
5
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
0
red rows below

Against other developers

7 date-assessed here · 260 developers, 976 date-assessed projects in United States
Median delay
Hudson·260 developers in United States
0.0 mo vs +4.5 mo
this developer 4.5 mo better
The typical project on each side.
Average delay
Hudson·260 developers in United States
+2.8 mo vs +7.4 mo
this developer 4.6 mo better
Both pulled by their worst few.
On time
Hudson·260 developers in United States
71% vs 56%
this developer 15 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Hudson·260 developers in United States
2.9 yrs vs 2.9 yrs
this developer is level
Start to completion, over 7 delivered here and 803 in the market.
The market here is United States: every other developer whose head office is in the same country, because planning regimes and reporting norms move together within one. It is not a city, a sector or a size band. Read the two delay figures together. A median close to the market with a much better average means no single disaster; the reverse means one project is carrying the record. Time to deliver runs from the earliest start we hold to the completion itself — a construction start where a source gave one, otherwise a sales launch, otherwise the launch year read as its January. A handover the sources place only inside a year is read as that December, so a duration is the widest the record allows rather than the flattering end of it. Only delivered projects dated at both ends count, so it is taken over fewer projects than the delay figures, and a long build is not a fault: a tower is not a villa run. Sourced figures only, both sides, and values taken from documents held on file are excluded here — a developer who shares their records should not score better than one who does not.

Construction start to handover

10 of 10 projects dated · 1 place
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
New York, United States
2018201920202021202220232024202520262027todayNEW YORK, UNITED STATES+1 moestimated+6 moestimated+1 moverified−4 moverified>9 mo earlyestimated+11.5 moverified+11 moverifiedon timeverifiedon timeverifiedon timeverified
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures. 2 turned out to be about something else — a phase, a neighbour, the wider masterplan — and are marked off-subject.

Building & Livability Ratings

Resident experience

5 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
6.7/ 10
Weighted judgment across build and operations · from 5 of 5 rated buildings
Little structure evidence (1 of 5 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
5.8/ 10
Fabric, services, waterproofing, envelope · from 1 of 5 rated buildings
Management & living
6.5/ 10
Upkeep, response times, amenities, community · from 2 of 5 rated buildings

Against other developers

5 rated here · 283 developers, 1449 rated buildings in United States
Overall rating
Hudson · 283 other developers in United States
6.7 vs 7.8
this developer 1.1 worse
The weighted verdict on each side. From 5 of 5 rated buildings here and 1449 in the market.
Structure & systems
Hudson · 283 other developers in United States
— vs 6.9
Too few buildings with this score here to compare (1 of 5)
Fabric and engineering only — fixed at handover. From 1 of 5 rated buildings here and 627 in the market.
Management & living
Hudson · 283 other developers in United States
— vs 7.4
Too few buildings with this score here to compare (2 of 5)
Upkeep and response — belongs to whoever runs the building now. From 2 of 5 rated buildings here and 1397 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.

By building

5 rated · 5 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
One ClintonBrooklyn Heights, New York133 units
7.2/ 10
—/ 10
—/ 10

CityRealty publishes an 89/100 editorial building rating, but no review count is stated and the available resident-review pages report no reviews. Because fewer than three individual written reviews were available and no qualifying aggregate with at least 10 reviews was found, the scoring rules require a null score; the old editorial and public-record evidence is not enough to create a current resident-experience score.

+ Multi-zoned heating and cooling+ In-unit washer and dryer+ Recent rodent inspections passed+ No recent bedbug infestations reported
− Historical elevator-maintenance complaint− Historical emergency electrical-lighting complaint− Resolved construction safety violations
+ Doorman+ Sky lounge+ Fitness center+ Landscaped communal outdoor space+ Resident and public library/community amenities

CityRealty describes One Clinton apartments as having multi-zoned heating and cooling, in-unit washers and dryers, and new-construction finishes. Augrented reports a 2022 elevator-maintenance complaint and a 2023 emergency electrical-lighting complaint, both closed, while its later rodent inspections passed and its listed bedbug filings showed zero infested units; these are public records rather than resident-review narratives.

The building-specific editorial review highlights a doorman, a 26th-floor “sky lounge,” fitness center, landscaped outdoor space, coworking space, community room, and children’s facilities. No building-specific resident review text was available on the resident-review pages read, so there is no verified resident feedback here about management speed, staff attitude, security, or common-area upkeep.

Riverwalk ParkRoosevelt Island, New York341 units
7.2/ 10
—/ 10
6.5/ 10

The 4.3/5 building rating from 40 reviews sets the anchor at 7.0/10. Reported severe fire/water-damage and recurring management/security complaints reduce that level, while repeated praise for staff, maintenance and amenities offsets part of the reduction, producing 6.5/10.

+ Modern new construction+ Maintenance reported as “tip top shape”
− Apartment fire− Sprinkler-related water damage− Elevator service interruption after fire
+ Responsive management+ Helpful assistant manager+ Pleasant concierge staff+ Good amenities and outdoor space+ Welcoming resident community
− Failed or delayed apartment-tour handling− Reported rude or classist leasing interactions− Security and disorder concerns− Smoking-policy enforcement concerns− Reported pest concerns

The building is described as a “sleek & modern new apartment building,” and one resident says maintenance keeps it in “tip top shape.” Countervailing reports describe an apartment fire that caused sprinkler water damage to lower floors; a contemporaneous local report says elevators were recalled to the lobby while damage was assessed, but no broad recurring structural defect was established.

Day-to-day feedback is mixed. Positive residents call Emir “outstanding,” say management is “very pro active,” and report “great management,” “tip top shape” maintenance and pleasant concierge staff; negative reviewers describe tour failures and rude treatment, while another says the building has roaches, disorder and weak enforcement of smoking and nuisance rules.

La Central A&BMelrose, New York496 units
6.7/ 10
5.8/ 10
6.5/ 10

The Google Reviews/Maps aggregate of 3.9/5 from 39 reviews sets the level; because the review base is below 10? No—the aggregate has 39 reviews, so it is eligible as the largest and only published building rating located. The score remains near the curve conversion because no second platform provides a comparable rated resident aggregate, while recurring positive and negative themes offset each other. Structure is lower than living because the report contains current public records of leaks, mold, heating, ventilation, flooring and elevator issues, but no structure-specific resident rating.

− Water leaks and mold reports− Heat and hot-water disruptions− Ventilation complaints− Flooring defects− Elevator safety violations
+ Attractive apartments+ Clean exterior+ Security praised+ Helpful staff praised+ Gym and rooftop terrace
− Wall-banging and tapping− Distressing noise− Individual staff complaint− Concerns about management explanation− Area safety concerns

The published building-condition record is materially negative, although it is not a resident-review rating: 600 Bergen had September 2026 records for an open slow water leak and emergency mold complaint, plus ceiling damage and defective flooring. 556 Bergen had 2026 complaints about ventilation and flooring and earlier emergency heat/hot-water complaints; these are public maintenance records, not forecasts or proof that every unit is affected.

Reviews describe attractive, clean apartments and positive security feedback: “Apartments are beautiful inside. outside clean… security is always on point,” while another praised “24/hr security... Gym, and rooftop terrace.” The negative side includes repeated wall-banging or tapping complaints and a serious individual complaint about support staff; the Google listing’s aggregate was 3.9/5 from 39 reviews.

Castleton HousingPort Richmond, New York48 units
6.2/ 10
—/ 10
—/ 10

Apartments.com publishes a 4.0/5 property rating but reports zero renter reviews, so it cannot be used as the anchor under the stated rules. No individual written reviews were available to score, and the remaining material consists of reporting and maintenance records rather than a qualifying review aggregate.

− Mold complaints− Plumbing defects− Bedbug infestation− Waste-line defects− Elevator-service complaint
− Reported drug activity− Harassment and trespassing reports− Attempted robbery reports− Public urination and defecation reports− Concerns about unresponsive management/agencies

No resident-written infrastructure reviews were located. A public-records compilation reports 2026 mold, bathtub, sink and waste-line complaints, a bedbug-abatement violation in apartment 4F, and a late-2023 elevator-service complaint; these are maintenance records rather than resident review scores.

The August 2024 Staten Island Advance report describes nearby residents’ quality-of-life and safety complaints and cites 243 911 calls and 18 arrests connected to the building since the start of that year. One quoted official said, “Not only has it not gotten better, it’s actually gotten worse,” while Project Hospitality disputed that it had previously received complaints and said it would work with the community.

The Peninsula Phase IHunts Point, Bronx, New York183 units
6.1/ 10
—/ 10
—/ 10

No platform rating with a stated review base was found, and only one written resident review was actually identifiable and read. The scoring rules require at least three written reviews when no qualifying platform anchor exists, so no score is assigned.

− Mold condition reported− Ventilation concerns− Paint/plaster deficiencies− Heat and hot-water complaints
+ New building+ Community amenities+ Affordable housing+ Resident recommendation+ Owner approval
− Truck traffic− Noise− Neighborhood safety concerns− Communication concerns during lease-up− Access concerns for lowest-income residents

The available building-condition material is primarily public housing-code and service-request reporting rather than resident review text. It records mold and ventilation issues, paint/plaster deficiencies, and repeated heat or hot-water complaints at 720 Tiffany Street; these are current-condition signals as of 2026, not evidence of a published resident rating.

The one resident review surfaced for 720 Tiffany Street described the building as brand new but complained, “To[o] many trucks pass through that area..to[o] much traffic,noise.” Earlier local reporting quoted community members worried that management had not communicated well enough and that income rules could exclude very low-income Hunts Point residents; those are lease-up concerns from 2021, not proof of current operations.

Only buildings that have reached handover are rated. 5 of 10 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
The Hudson Companies Inc.
Headquarters
826 Broadway, New York, United States
10003
Founded
1986
US
Entity type
PRIVATE
Revenue
USD 21.05 million annual revenue
Business model
offplan for sale, build to sell institutional, commercial, mixed use, masterplan

Partners

14 partners
Bank of America
funder
Citibank
funder
JPMorgan Chase Bank
funder
Wells Fargo Bank
funder
NYC Housing Preservation & Development
government partner
New York City Housing Authority
government partner
Roosevelt Island Operating Corporation
government partner
Project Renewal
partner
Breaking Ground
partner
CAMBA Housing Ventures
partner
Jonathan Rose Companies
joint venture
The Related Companies
joint venture
Property Resources Corporation
joint venture
Gilbane, Inc.
contractor

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Bank of America
value seen: Bank of America
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
LENDERS
value seen: FUNDER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Citibank
value seen: Citibank
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
LENDERS
value seen: FUNDER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Jonathan Rose Companies
value seen: Jonathan Rose Companies
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
DEVELOPMENT PARTNERS
value seen: JV_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• The Related Companies
value seen: The Related Companies
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
DEVELOPMENT PARTNERS
value seen: JV_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Property Resources Corporation
value seen: Property Resources Corporation
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
DEVELOPMENT PARTNERS
value seen: JV_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Gilbane, Inc.
value seen: Gilbane, Inc.
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
DEVELOPMENT PARTNERS
value seen: CONTRACTOR
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• JPMorgan Chase Bank
value seen: JPMorgan Chase Bank
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
LENDERS
value seen: FUNDER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Wells Fargo Bank
value seen: Wells Fargo Bank
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
LENDERS
value seen: FUNDER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• NYC Housing Preservation & Development
value seen: NYC Housing Preservation & Development
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
GOVERNMENT AGENCIES
value seen: GOVERNMENT_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• New York City Housing Authority
value seen: New York City Housing Authority
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
GOVERNMENT AGENCIES
value seen: GOVERNMENT_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Roosevelt Island Operating Corporation
value seen: Roosevelt Island Operating Corporation
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
GOVERNMENT AGENCIES
value seen: GOVERNMENT_PARTNER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Project Renewal
value seen: Project Renewal
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
NON PROFIT PARTNERS
value seen: OTHER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• Breaking Ground
value seen: Breaking Ground
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
NON PROFIT PARTNERS
value seen: OTHER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: name

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
• CAMBA Housing Ventures
value seen: CAMBA Housing Ventures
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Sources: partner type

COMPANYdate not shown in source

The Hudson Companies

Hudson Companies
NON PROFIT PARTNERS
value seen: OTHER
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/ee/44/ee448ed6-36ad-4d9f-a54a-45072032d6a1/fact_sheet_2024_v2.pdf

Registrations & licences

COMPANY NUMBER1109559
New York Department of State · US · ACTIVE
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries
United Statesactive 10 projects tracked

What they build

5 types
Residential, for rent9 of 10
Retail6 of 10
Mixed use6 of 10
Other4 of 10
Residential, for sale1 of 10
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
WF
William Fowler
William Fowler co-founded Hudson in 1986 and remains a principal, although the company describes him as semi-retired. He continues to advise management and invest in projects; his documented education is Yale College and Harvard Business School.
Current title
Principal & Co-Founder
since 1986
Experience
no career length stated
Companies before
none sourced
Education
Yale CollegeBachelor of Arts
Harvard Business SchoolMaster of Business Administration
Other boards
none sourced
Known for
FounderSemi-retiredYaleHarvard MBA
https://linkedin.com/in/william-fowler-3795259

Sources: degree

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Bill earned a Bachelor of Arts from Yale College
value seen: Bachelor of Arts
https://www.hudsoninc.com/team/william-fowler/

Sources: institution

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Bill earned a Bachelor of Arts from Yale College
value seen: Yale College
https://www.hudsoninc.com/team/william-fowler/

Sources: degree

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Master of Business Administration from the Harvard Business School
value seen: Master of Business Administration
https://www.hudsoninc.com/team/william-fowler/

Sources: institution

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Master of Business Administration from the Harvard Business School
value seen: Harvard Business School
https://www.hudsoninc.com/team/william-fowler/

Sources: role type

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
William Fowler was one of the founders of Hudson in 1986
value seen: founder
value paraphrased from this source
https://www.hudsoninc.com/team/william-fowler/

Sources: since

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
William Fowler was one of the founders of Hudson in 1986
value seen: 1986
https://www.hudsoninc.com/team/william-fowler/

Sources: summary

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
William Fowler was one of the founders of Hudson in 1986 and remains a principal of the firm. Though more recently semi-retired, he continues to contribute to and be available to the talented management and staff of the firm and invest in the projects.
value seen: William Fowler co-founded Hudson in 1986 and remains a principal, although the company describes him as semi-retired. He continues to advise management and invest in projects; his documented education is Yale College and Harvard Business School.
value paraphrased from this source
https://www.hudsoninc.com/team/william-fowler/

Sources: tags

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
one of the founders of Hudson in 1986
value seen: Founder
value paraphrased from this source
https://www.hudsoninc.com/team/william-fowler/

Sources: tags

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Though more recently semi-retired
value seen: Semi-retired
value paraphrased from this source
https://www.hudsoninc.com/team/william-fowler/

Sources: tags

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Bill earned a Bachelor of Arts from Yale College
value seen: Yale
https://www.hudsoninc.com/team/william-fowler/

Sources: tags

COMPANYdate not shown in source

William Fowler | Hudson Inc.

Hudson Inc
Master of Business Administration from the Harvard Business School
value seen: Harvard MBA
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/team/william-fowler/

Sources: title

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
Principal & Co-Founder William Fowler
value seen: Principal & Co-Founder
https://www.hudsoninc.com/team/
DK
David Kramer
David Kramer has led Hudson’s development work since joining in 1995 and is currently identified by Hudson as president. His track record includes Cornell Tech, Roosevelt Island’s Riverwalk and One Clinton, and he serves on the Sylvia Center board.
Current title
President
since 2012
Experience
no career length stated
Companies before
none sourced
Education
Yale UniversityBachelor Degree
Other boards
Sylvia Center
Known for
PresidentJoined Hudson 1995YaleNYC housing

Sources: degree

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
David has a Bachelor Degree from Yale University
value seen: Bachelor Degree
https://www.hudsoninc.com/team/David-Kramer/

Sources: institution

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
David has a Bachelor Degree from Yale University
value seen: Yale University
https://www.hudsoninc.com/team/David-Kramer/

Sources: other boards

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
currently serves on the board of the Sylvia Center
value seen: Sylvia Center
https://www.hudsoninc.com/team/David-Kramer/

Sources: quote

PRESS2024-01-31

Hudson Companies’ David Kramer Goes Big in Brooklyn And Beyond – Commercial Observer

Commercial Observer
I got bumped up to CEO, and I’ve bumped myself down to president again.
value seen: I got bumped up to CEO, and I’ve bumped myself down to president again.
held out of the figures · the value did not fit the record it was filed under
https://commercialobserver.com/2024/01/david-kramer-brooklyn-interview/

Sources: url

PRESS2024-01-31

Hudson Companies’ David Kramer Goes Big in Brooklyn And Beyond – Commercial Observer

Commercial Observer
I got bumped up to CEO, and I’ve bumped myself down to president again.
value seen: https://commercialobserver.com/2024/01/david-kramer-brooklyn-interview/
held out of the figures · the value did not fit the record it was filed under
https://commercialobserver.com/2024/01/david-kramer-brooklyn-interview/

Sources: since

PRESS2022-10-11

The Hudson Cos. names Koffman president and appoints Kramer CEO

New York Real Estate Journal
David Kramer, the company’s president since 2012
value seen: 2012
https://nyrej.com/the-hudson-cos-names-koffman-president-and-appoints-kramer-ceo

Sources: summary

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
David joined Hudson in 1995 and has played a role in many of Hudson’s most exciting achievements of the past 3 decades including the world’s largest Passive House building, the House at Cornell Tech, the development of the Riverwalk neighborhood on Roosevelt Island, and the redevelopment of the Brooklyn Heights library, One Clinton.
value seen: David Kramer has led Hudson’s development work since joining in 1995 and is currently identified by Hudson as president. His track record includes Cornell Tech, Roosevelt Island’s Riverwalk and One Clinton, and he serves on the Sylvia Center board.
value paraphrased from this source
https://www.hudsoninc.com/team/David-Kramer/

Sources: tags

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
President David Kramer
value seen: President
https://www.hudsoninc.com/team/

Sources: tags

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
David joined Hudson in 1995
value seen: Joined Hudson 1995
https://www.hudsoninc.com/team/David-Kramer/

Sources: tags

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
Bachelor Degree from Yale University
value seen: Yale
https://www.hudsoninc.com/team/David-Kramer/

Sources: tags

COMPANYdate not shown in source

David Kramer | Hudson Inc.

Hudson Inc
David is a native New Yorker who loves developing housing
value seen: NYC housing
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/team/David-Kramer/

Sources: title

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
President David Kramer
value seen: President
https://www.hudsoninc.com/team/
SG
Sally Gilliland
Sally Gilliland is Hudson’s principal and COO and a licensed architect with more than 30 years of experience. She joined Hudson in 2001 and guides design and construction, with a focus on design excellence from urban planning through interiors.
Current title
Principal & Chief Operating Officer
since 2001
Experience
30+ years experience
Companies before
none sourced
Education
Trinity CollegeBachelor of Arts in Art History
Columbia UniversityMaster of Architecture
Other boards
none sourced
Known for
COOLicensed architectColumbia M.Arch
https://linkedin.com/in/sally-gilliland-28134688
It’s a combination of factors – ranging from budget impacts (cost of land, financing, construction, investment returns) weighed alongside location, access to transit, and potential rent or sales prices. Design 2147 https://design2147.com/news/urban-development-qa-with-sally-gilliland/

Sources: degree

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Bachelor of Arts In Art History from Trinity College
value seen: Bachelor of Arts In Art History
https://www.hudsoninc.com/team/sally-gilliland/

Sources: institution

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Bachelor of Arts In Art History from Trinity College
value seen: Trinity College
https://www.hudsoninc.com/team/sally-gilliland/

Sources: degree

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Master of Architecture from Columbia University
value seen: Master of Architecture
https://www.hudsoninc.com/team/sally-gilliland/

Sources: institution

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Master of Architecture from Columbia University
value seen: Columbia University
https://www.hudsoninc.com/team/sally-gilliland/

Sources: quote

PRESS2024-09-26

Urban Development Q&A with Sally Gilliland of Hudson Cos.

Design 2147
It’s a combination of factors – ranging from budget impacts (cost of land, financing, construction, investment returns) weighed alongside location, access to transit, and potential rent or sales prices.
value seen: It’s a combination of factors – ranging from budget impacts (cost of land, financing, construction, investment returns) weighed alongside location, access to transit, and potential rent or sales prices.
https://design2147.com/news/urban-development-qa-with-sally-gilliland/

Sources: url

PRESS2024-09-26

Urban Development Q&A with Sally Gilliland of Hudson Cos.

Design 2147
It’s a combination of factors – ranging from budget impacts (cost of land, financing, construction, investment returns) weighed alongside location, access to transit, and potential rent or sales prices.
value seen: https://design2147.com/news/urban-development-qa-with-sally-gilliland/
https://design2147.com/news/urban-development-qa-with-sally-gilliland/

Sources: since

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
She joined Hudson in 2001
value seen: 2001
https://www.hudsoninc.com/team/sally-gilliland/

Sources: summary

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Sally is a licensed architect with over thirty years of experience. She joined Hudson in 2001 and has guided the design and construction of the firm’s projects throughout her tenure. Her focus is on achieving design excellence at all levels, from large scale urban planning down to apartment interiors.
value seen: Sally Gilliland is Hudson’s principal and COO and a licensed architect with more than 30 years of experience. She joined Hudson in 2001 and guides design and construction, with a focus on design excellence from urban planning through interiors.
value paraphrased from this source
https://www.hudsoninc.com/team/sally-gilliland/

Sources: tags

PRESS2024-09-26

Urban Development Q&A with Sally Gilliland of Hudson Cos.

Design 2147
Principal & COO of Hudson Companies
value seen: COO
https://design2147.com/news/urban-development-qa-with-sally-gilliland/

Sources: tags

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Sally is a licensed architect
value seen: Licensed architect
https://www.hudsoninc.com/team/sally-gilliland/

Sources: tags

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
over thirty years of experience
value seen: 30+ yrs experience
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/team/sally-gilliland/

Sources: tags

COMPANYdate not shown in source

Sally Gilliland | Hudson Inc.

Hudson Inc
Master of Architecture from Columbia University
value seen: Columbia M.Arch
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/team/sally-gilliland/

Sources: title

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
Principal & Chief Operating Officer Sally Gilliland
value seen: Principal & Chief Operating Officer
https://www.hudsoninc.com/team/
SL
Scott Lorber
Scott Lorber manages Hudson’s financial risks and oversees financial planning and reporting, treasury management and human resources. Hudson says he has more than 13 years of public-accounting experience and holds a BS in accounting and CPA qualification.
Current title
Principal & Chief Financial Officer
Experience
13+ years public accounting
Companies before
none sourced
Education
University of Maryland, Robert H. Smith School of BusinessBachelor of Science in Accounting
Other boards
none sourced
Known for
CFOCPAUniversity of Maryland

Sources: degree

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Bachelor of Science in Accounting from the University of Maryland’s Robert H. Smith School of Business
value seen: Bachelor of Science in Accounting
https://www.hudsoninc.com/team/scott-lorber/

Sources: institution

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Bachelor of Science in Accounting from the University of Maryland’s Robert H. Smith School of Business
value seen: University of Maryland, Robert H. Smith School of Business
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/team/scott-lorber/

Sources: summary

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Scott is responsible for managing the financial risks of Hudson and overseeing Hudson’s financial planning and reporting, treasury management, and human resources functions. Scott has over 13 years of public accounting experience.
value seen: Scott Lorber manages Hudson’s financial risks and oversees financial planning and reporting, treasury management and human resources. Hudson says he has more than 13 years of public-accounting experience and holds a BS in accounting and CPA qualification.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/team/scott-lorber/

Sources: tags

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
Principal & Chief Financial Officer Scott Lorber
value seen: CFO
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/team/

Sources: tags

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Scott has over 13 years of public accounting experience
value seen: 13+ yrs public accounting
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/team/scott-lorber/

Sources: tags

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Scott ... is a Certified Public Accountant
value seen: CPA
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/team/scott-lorber/

Sources: tags

COMPANYdate not shown in source

Scott Lorber | Hudson Inc.

Hudson Inc
Bachelor of Science in Accounting from the University of Maryland’s Robert H. Smith School of Business
value seen: University of Maryland
https://www.hudsoninc.com/team/scott-lorber/

Sources: title

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
Principal & Chief Financial Officer Scott Lorber
value seen: Principal & Chief Financial Officer
https://www.hudsoninc.com/team/
IH
Isaac Henderson
Isaac Henderson joined Hudson in May 2026 as principal and co-head of development after serving as a managing director at Rockefeller Group. His documented background spans Lendlease, L&M, Community Preservation Corporation and BRIDGE Housing; he oversees Hudson’s mixed-use portfolio.
Current title
Principal, Co-Head of Development
since May 2026
Experience
20+ years real estate
Companies before
Rockefeller GroupLendleaseL&MCommunity Preservation CorporationBRIDGE Housing Corporation
Education
The University of North Carolina at Chapel HillMasters, City and Regional Planning
Other boards
Friends Seminary — Head of Board of Trustees
Known for
Co-Head of Developmentex-Rockefeller GroupUNC Chapel Hill
https://linkedin.com/in/isaac-henderson-65443a15
The Hudson Companies has delivered premier mixed-use developments for decades and it’s an honor to join this incredible team and further our mission of building housing for all. Commercial Observer May 21, 2026https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: degree

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Masters, City and Regional Planning at The University of North Carolina at Chapel Hill
value seen: Masters, City and Regional Planning
https://linkedin.com/in/isaac-henderson-65443a15

Sources: institution

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Masters, City and Regional Planning at The University of North Carolina at Chapel Hill
value seen: The University of North Carolina at Chapel Hill
https://linkedin.com/in/isaac-henderson-65443a15

Sources: other boards

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Head of Board of Trustees - Friends Seminary (Current)
value seen: Friends Seminary — Head of Board of Trustees
held out of the figures · the quote does not carry this value
https://linkedin.com/in/isaac-henderson-65443a15

Sources: previous companies

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Managing Director - Rockefeller Group
value seen: Rockefeller Group
https://linkedin.com/in/isaac-henderson-65443a15

Sources: previous companies

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Development Director - Lendlease
value seen: Lendlease
https://linkedin.com/in/isaac-henderson-65443a15

Sources: previous companies

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Director - Essex Crossing - L&M
value seen: L&M
https://linkedin.com/in/isaac-henderson-65443a15

Sources: previous companies

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Vice President - Community Preservation Corporation
value seen: Community Preservation Corporation
https://linkedin.com/in/isaac-henderson-65443a15

Sources: previous companies

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Project Manager - BRIDGE Housing Corporation
value seen: BRIDGE Housing Corporation
https://linkedin.com/in/isaac-henderson-65443a15

Sources: date

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
May 21, 2026
value seen: May 21, 2026
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: publisher

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
Commercial Observer
value seen: Commercial Observer
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: quote

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
The Hudson Companies has delivered premier mixed-use developments for decades and it’s an honor to join this incredible team and further our mission of building housing for all.
value seen: The Hudson Companies has delivered premier mixed-use developments for decades and it’s an honor to join this incredible team and further our mission of building housing for all.
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: url

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
The Hudson Companies has delivered premier mixed-use developments for decades and it’s an honor to join this incredible team and further our mission of building housing for all.
value seen: https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: since

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
May 2026 - Present
value seen: May 2026
https://linkedin.com/in/isaac-henderson-65443a15

Sources: summary

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
Real estate developer the Hudson Companies has hired Isaac Henderson, formerly a managing director at Rockefeller Group, and its co-head of development.
value seen: Isaac Henderson joined Hudson in May 2026 as principal and co-head of development after serving as a managing director at Rockefeller Group. His documented background spans Lendlease, L&M, Community Preservation Corporation and BRIDGE Housing; he oversees Hudson’s mixed-use portfolio.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: tags

COMPANYdate not shown in source

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Hudson Inc · carried by commercialobserver.com
Principal, Co-Head of Development
value seen: Co-Head of Development
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: tags

COMPANYdate not shown in source

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Hudson Inc · carried by commercialobserver.com
formerly a managing director at Rockefeller Group
value seen: ex-Rockefeller Group
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: tags

COMPANYdate not shown in source

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Hudson Inc · carried by commercialobserver.com
bringing decades of experience
value seen: 20+ yrs real estate
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/

Sources: tags

SOCIAL2026-09-08

Isaac Henderson

LinkedIn
Masters, City and Regional Planning at The University of North Carolina at Chapel Hill
value seen: UNC Chapel Hill
held out of the figures · the quote does not carry this value
https://linkedin.com/in/isaac-henderson-65443a15

Sources: title

PRESS2026-05-21

Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development – Commercial Observer

Commercial Observer
Hudson Companies Hires Isaac Henderson as Principal, Co-Head of Development
value seen: Principal, Co-Head of Development
https://commercialobserver.com/2026/05/hudson-companies-hires-isaac-henderson-principal-co-head-development/
LS
Laszlo Syrop
Laszlo Syrop leads Hudson’s acquisitions and new-business functions. Before Hudson he worked at HomeRiver Group, Lee Equity Partners, Boston Consulting Group and Related Companies, and holds economics and MBA credentials from Brown and Wharton.
Current title
Principal & Head of Acquisitions
since May 14, 2025
Experience
no career length stated
Companies before
HomeRiver GroupLee Equity PartnersBoston Consulting GroupRelated Companies
Education
Brown UniversityBachelor of Arts in Economics
The Wharton School, University of PennsylvaniaMaster of Business Administration
Other boards
none sourced
Known for
Head of AcquisitionsPrincipalex-BCGWharton MBABrown economics
https://linkedin.com/in/laszlo-syrop-8a42a44
You can create as much zoning floor as you want. If the unit economics don’t work, a million unprofitable FAR is basically zero. Range NYC March 29, 2026https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis

Sources: degree

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Bachelor of Arts in Economics from Brown University
value seen: Bachelor of Arts in Economics
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: institution

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Bachelor of Arts in Economics from Brown University
value seen: Brown University
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: degree

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Master of Business Administration from the Wharton School at the University of Pennsylvania
value seen: Master of Business Administration
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: institution

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Master of Business Administration from the Wharton School at the University of Pennsylvania
value seen: The Wharton School, University of Pennsylvania
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: previous companies

SOCIAL2026-10-09

Laszlo Syrop

LinkedIn
VP of Acquisitions and Operations at HomeRiver Group
value seen: HomeRiver Group
https://linkedin.com/in/laszlo-syrop-8a42a44

Sources: previous companies

SOCIAL2026-10-09

Laszlo Syrop

LinkedIn
roles at Lee Equity Partners
value seen: Lee Equity Partners
https://linkedin.com/in/laszlo-syrop-8a42a44

Sources: previous companies

SOCIAL2026-10-09

Laszlo Syrop

LinkedIn
held roles at ... the Boston Consulting Group
value seen: Boston Consulting Group
https://linkedin.com/in/laszlo-syrop-8a42a44

Sources: previous companies

SOCIAL2026-10-09

Laszlo Syrop

LinkedIn
Summer Associate ... Related Companies
value seen: Related Companies
https://linkedin.com/in/laszlo-syrop-8a42a44

Sources: date

PRESS2026-03-29

NYC Has a Housing Crisis, Not an Affordability Crisis

Range NYC
publishedDate 2026-03-29
value seen: March 29, 2026
https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis

Sources: publisher

PRESS2026-03-29

NYC Has a Housing Crisis, Not an Affordability Crisis

Range NYC
Range NYC
value seen: Range NYC
https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis

Sources: quote

PRESS2026-03-29

NYC Has a Housing Crisis, Not an Affordability Crisis

Range NYC
“You can create as much zoning floor as you want. If the unit economics don’t work, a million unprofitable FAR is basically zero.”
value seen: You can create as much zoning floor as you want. If the unit economics don’t work, a million unprofitable FAR is basically zero.
https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis

Sources: url

PRESS2026-03-29

NYC Has a Housing Crisis, Not an Affordability Crisis

Range NYC
“You can create as much zoning floor as you want. If the unit economics don’t work, a million unprofitable FAR is basically zero.”
value seen: https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis
https://rangenyc.substack.com/p/nyc-has-a-housing-crisis-not-an-affordability-crisis

Sources: since

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
promotion of Laszlo Syrop ... to the position of Principal
value seen: May 14, 2025
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: summary

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
In his capacity as Head of Acquisitions, Syrop leads Hudson’s efforts in identifying, evaluating, and securing new development and investment opportunities across all lines of business.
value seen: Laszlo Syrop leads Hudson’s acquisitions and new-business functions. Before Hudson he worked at HomeRiver Group, Lee Equity Partners, Boston Consulting Group and Related Companies, and holds economics and MBA credentials from Brown and Wharton.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: tags

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
In his capacity as Head of Acquisitions, Syrop leads Hudson’s efforts
value seen: Head of Acquisitions
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: tags

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
promotion ... to the position of Principal
value seen: Principal
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: tags

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
held roles at ... the Boston Consulting Group
value seen: ex-BCG
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: tags

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Master of Business Administration from the Wharton School
value seen: Wharton MBA
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: tags

COMPANY2025-05-14

The Hudson Companies Inc.

Hudson Inc
Bachelor of Arts in Economics from Brown University
value seen: Brown economics
held out of the figures · the quote does not carry this value
https://www.hudsoninc.com/media/filer_public/05/4b/054b88ba-987e-4257-924f-a4ed77e4c937/hudson_co_-_laszlo_syrop_promotion.pdf

Sources: title

COMPANYdate not shown in source

Team | Hudson Inc.

Hudson Inc
Principal & Head of Acquisitions Laszlo Syrop
value seen: Principal & Head of Acquisitions
https://www.hudsoninc.com/team/

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases
The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

10 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
The Peninsula Phase IINew York, United States
Hunts Point, Bronx
residential for rent, retail, mixed use3591——USD 297m
estimated cost
—20192019-07-16Jul 2026Aug 2026+1.0 mo
(+1.0 to +1.0)
estimatedcompleted
Barbara Kleiman Shelter Phase 1New York, United States
East Williamsburg, Brooklyn
residential for rent, other2001—54,000 sq ftUSD 66m
construction loan
—20182018-09-13Oct 2025Apr 2026+6.0 mo
(+6.0 to +6.0)
estimatedcompleted
The Arcadian at 975 NostrandNew York, United States
Crown Heights, Brooklyn
residential for rent, retail, mixed use32819 stories350,000 sq ftUSD 135m
construction loan
—20212021-08-26Sep 2025 – Nov 2025Nov 2025+1.0 mo
(0.0 to +2.0)
sourcedcompleted
Logan FountainNew York, United States
Cypress Hills
residential for rent, retail, mixed use343113 stories318,000 sq ftUSD 214m
estimated cost
—2022December 14, 2022Sep 2024 – Dec 2024Jan 2024 – Dec 2024−4.0 mo
(−11.0 to +3.0)
sourcedcompleted
Riverwalk HeightsNew York, United States
Roosevelt Island
residential for rent357130—USD 185m
construction loan
—20222022-11-14May 2025 – Aug 2025Jan 2024 – Dec 2024more than 9 months earlyestimatedcompleted
The Peninsula Phase INew York, United States
Hunts Point, Bronx
residential for rent, retail, mixed use1831——USD 121.5m
estimated cost
—20192019-11-06Jan 2021 – Dec 2021Jun 2022+11.5 mo
(+6.0 to +17.0)
sourcedcompleted
La Central A&BNew York, United States
Melrose
residential for rent, retail, other, mixed use496113 stories600,000 sq ftUSD 334m
estimated cost
—20182018-04Jul 2020Jun 2021+11.0 mo
(+11.0 to +11.0)
sourcedcompleted
Castleton HousingNew York, United States
Port Richmond
residential for rent, other4816 stories41,000 sq ftUSD 27m
estimated cost
—20192019Jan 2021 – Dec 2021Jan 2021 – Dec 20210.0 mo
(−11.0 to +11.0)
sourcedcompleted
Riverwalk ParkNew York, United States
Roosevelt Island
residential for rent341121 stories252,000 sq ftUSD 135.8m
estimated cost
—20192019-08-13Jan 2021 – Dec 2021Jan 2021 – Dec 20210.0 mo
(−11.0 to +11.0)
sourcedcompleted
One ClintonNew York, United States
Brooklyn Heights
residential for sale, retail, other, mixed use133138-story condominium tower405,000 sq ftUSD 426m
other
—2019January 8, 2019Jan 2020 – Dec 2020Jan 2020 – Dec 20200.0 mo
(−11.0 to +11.0)
sourcedcompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

7 found
PROJECT AWARD Winner 2023
Excellence in Market-Rate Housing Development · One Clinton
One Clinton won the Urban Land Institute award for Excellence in Market-Rate Housing Development; the ULI event page identifies The Hudson Companies’ development team with the winning project.
PROJECT AWARD Winner 2023
Excellence in Exterior, Interior, and Outdoor Space · Castleton Housing
The Hudson Companies’ awards page reports Castleton Housing as the recipient of the Staten Island Chamber of Commerce award for Excellence in Exterior, Interior, and Outdoor Space.
Staten Island Chamber of Commerce · https://www.hudsoninc.com/awards-press/awards/
SUSTAINABILITY Winner 2021
Buildings of Excellence · Greenpoint Hospital
The Hudson Companies’ awards page reports Greenpoint Hospital as a Buildings of Excellence award recipient in NYSERDA’s multifamily-building competition.
New York State Energy Research and Development Authority (NYSERDA) · https://www.hudsoninc.com/awards-press/awards/
PROJECT AWARD Winner 2021
Blue Ribbon Award for Design Excellence · Greenpoint Hospital
The Hudson Companies’ awards page reports Greenpoint Hospital as the recipient of AIA New York’s Blue Ribbon Award for Design Excellence.
PROJECT AWARD Winner 2020
2020 AN Best of Design Award · The Peninsula
The Hudson Companies’ awards page reports The Peninsula as a recipient of The Architect’s Newspaper’s 2020 AN Best of Design Award.
The Architect’s Newspaper · https://www.hudsoninc.com/awards-press/awards/
SUSTAINABILITY Certified 2019
LEED for Homes Gold · The Clark
The Hudson Companies’ awards page reports The Clark as having received LEED for Homes Gold certification from the U.S. Green Building Council.
U.S. Green Building Council · https://www.hudsoninc.com/awards-press/awards/
COMPANY AWARD Winner 2011
Developer of the Year
The New York Housing Conference’s past-honorees list records The Hudson Companies, Inc. as Developer of the Year; this is an older recognition and is included as a company-defining award.
New York Housing Conference · https://thenyhc.org/honorees/

Risks

Risk flags

4 found
SAFETY / LABOUR Accident reported as September 11, 2018; Supreme Court order October 2, 2024; Appellate Division decision February 5, 2026
A New York Appellate Division opinion affirmed partial summary judgment against the project owner/general contractor on a Labor Law §240(1) claim after a worker was struck by unsecured, leaning 250-pound doorframes; the court dismissed the related third-party claims against the hoist/crane defendants, while Hudson Companies was named as a defendant in the action. The underlying accident occurred at the Athena Housing project, and the decision does not establish that Hudson itself caused the unsafe condition.
LEGAL Reported April 6, 2023; complaint filed in April 2023
Four Parkline tenants filed a proposed class-action lawsuit against Hudson affiliate Hudson CBD Flatbush LLC, alleging that rent concessions were used to register higher rents and that concessions were withdrawn at renewal, producing unlawful rent overcharges; the article reported the allegations and a proposed class but no final merits resolution.
DELIVERY DELAY Delay reported January 23, 2017; current Hudson project page lists anticipated construction in 2026 and completion in 2028
Gowanus Green, a Hudson-led joint venture project, was reported in 2017 as having missed its repeatedly pushed completion target and lacking a reliable target date because of environmental remediation and approval issues; Hudson’s current project page lists completion as 2028 and construction as anticipated in 2026, which is a future commitment rather than evidence of completion as of October 15, 2026.
DELIVERY DELAY 2017-01-23; 2024-11-18; research date 2026-10-15
Gowanus Green, a joint venture involving The Hudson Companies (Gowanus Green Partners), remained effectively on indefinite hold as of November 18, 2024: its earlier 2017 completion target was no longer realistic, and construction was still contingent on unresolved additional environmental remediation, despite Hudson’s website later showing a 2028 completion estimate; this documents delay/non-delivery but not cancellation, and the reported environmental and regulatory constraints do not by themselves establish Hudson parent liability.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 15, 2026 this month
Profile last researchedOctober 15, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.