Artificial Intelligence
Builders Company
Developers/Monadnock Development
MD
Monadnock DevelopmentBrooklyn, United States · founded 2006 · 1 active markets
PRIVATE

Monadnock Development builds affordable, mixed-income, market-rate, luxury, and mixed-use housing in New York City for low-, middle-, and market-income residents, combining development, construction, financing, rehabilitation, property management, and asset management to create lasting neighborhood assets with community and commercial uses.

Years in business
20
founded 2006
LinkedIn headcount
18
employees, as shown on LinkedIn · size band 11–50
Portfolio value
USD 2.9 billion
over the past decade
Total projects
14
across the company’s whole history
Units delivered
over 8,000 units
as the company states it
Projects last researched October 15, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
MONADNOCK DEVELOPMENT LLC1
Headquarters
300 Huntington Street1, Brooklyn1, US
Founded
20061
Entity type
PRIVATE1
Business model
mixed use1, masterplan1, other1
Markets
1 market listed
What they build
Residential, for rent (8 of 9) · Retail (2 of 9) · Mixed use (2 of 9)
Full dossier in About →

Delivery record

2 date-assessed of 9 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 1 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
9
within the rolling ten-year window
Median delay
+7.0 mo
the middle of 2 scored projects
Average delay
+7.0 mo
the same projects, pulled by the worst
Average time to deliver
—
1 delivered project with a dated start — needs 3
Worst slip
+12.0 mo
Nehemiah Spring Creek Phase 4C · +5.0 to +19.0
1
early or less than 6 months late
6 to 12 months late
1
yellow rows below
Over 12 months late
0
red rows below

Against other developers

2 date-assessed projects here
Not enough info yet.
Projects and timelines in Track Record →

Resident experience

2 of 9 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
5.5/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (0 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
—/ 10
Fabric, services, waterproofing, envelope · from 0 of 2 rated buildings
Management & living
6.1/ 10
Upkeep, response times, amenities, community · from 1 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in United States yet to compare against.
Ratings by building →

Awards & recognition

  • COMPANY AWARD Winner 2021 (announced June 22, 2021)
    Visionary Leadership in Land Use Award
    The award recognized Kirk Goodrich, president of Monadnock Development, for a body of work and civic engagement described as having a transformational impact on New York’s real-estate community and industry.
  • PROJECT AWARD Winner 2020 (winners announced November 2, 2020; reported December 1, 2020)
    Excellence in Affordable Housing Development · One Flushing
    One Flushing won ULI New York’s Excellence in Affordable Housing Development award; the winning development team included Asian Americans for Equality, HANAC, and Monadnock Development.
  • GOVERNMENT RECOGNITION Winner 2018
    Big Apple Brownfield Award for Environmental Protection · One Flushing
    One Flushing received the 2018 Big Apple Brownfield Award for Environmental Protection; the source identifies Monadnock Development, Asian Americans for Equality, and HANAC as the developers and describes the site’s brownfield remediation and unrestricted-use cleanup.
  • 1 more in Awards
All awards →

Risks & source coverage

  • SAFETY / LABOUR Filed January 15, 2026; docket remained open through May 18, 2026 A civil labor-and-employment lawsuit was filed against Monadnock Development LLC in Kings County Supreme Court; the publicly available docket identifies the case as open as of the latest docket entries, but does not state the underlying allegations or any adjudicated outcome.
  • LEGAL Filed January 25, 2024; partial discontinuance recorded December 4, 2025 Monadnock Development LLC and related project entities sued Capitol Specialty Insurance Corporation and another insurer in a coverage dispute; the case was reported as open, with a partial discontinuance recorded on December 4, 2025, and no final merits outcome established by the retrieved docket.
  • LEGAL Injury July 16, 2022; court decision April 8, 2026 In litigation arising from a July 16, 2022 construction-site injury, Monadnock Development LLC was a plaintiff seeking insurance defense and indemnification; the court’s April 8, 2026 decision denied the insurer’s motion to add counterclaims, while the underlying coverage motions remained undecided.
  • 2 more in Risk & Sources
Record status
active
Company sources
122 source entries across 116 fields
Projects tracked
10 · 9 completed in assessment
All flags and sources →

Track Record

Delivery record

2 date-assessed of 9 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 1 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
9
within the rolling ten-year window
Median delay
+7.0 mo
the middle of 2 scored projects
Average delay
+7.0 mo
the same projects, pulled by the worst
Average time to deliver
—
1 delivered project with a dated start — needs 3
Worst slip
+12.0 mo
Nehemiah Spring Creek Phase 4C · +5.0 to +19.0
1
early or less than 6 months late
6 to 12 months late
1
yellow rows below
Over 12 months late
0
red rows below

Against other developers

2 date-assessed projects here
Not enough info yet.

Construction start to handover

9 of 9 projects dated · 1 place
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
New York, United States
201920202021202220232024202520262027todayNEW YORK, UNITED STATEScompleted, no target publishedon timeestimated+12 moverified+11.5 moestimated+12 moestimated>9 mo earlyestimatedcompleted, no target published+2 moverifiedcompleted, no target published
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures. 1 turned out to be about something else — a phase, a neighbour, the wider masterplan — and is marked off-subject.

Building & Livability Ratings

Resident experience

2 of 9 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
5.5/ 10
Weighted judgment across build and operations · from 2 of 2 rated buildings
Little structure evidence (0 of 2 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
—/ 10
Fabric, services, waterproofing, envelope · from 0 of 2 rated buildings
Management & living
6.1/ 10
Upkeep, response times, amenities, community · from 1 of 2 rated buildings

Against other developers

not enough rated buildings yet
Not enough rated buildings in United States yet to compare against.

By building

2 rated · 7 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
Compass Six ResidencesCrotona Park East and West Farms, New York261 units
6.1/ 10
—/ 10
6.1/ 10

The largest published review base located is the 18-review, 3.7/5 aggregate for the broader Compass Residences cluster, not Compass Six alone; under the supplied conversion curve it sets a 6.1 baseline. The building-specific material adds maintenance and safety concerns, but these are not used to invent a separate resident-review score or a structure score, and no second qualifying platform rating was found.

+ New construction+ Elevator+ Energy-efficient appliances
− Heat and hot-water complaints− Elevator maintenance complaints− Garbage-storage violations− Door and bathroom ventilation issues− Pest and paint/plaster complaints
+ Gym/fitness center+ Outdoor recreation space+ Shared laundry+ Bike storage+ On-site resident manager
− Unlocked lobby reported− Noise and late parties reported− Safety concerns reported− Unresponsive management reported− Upkeep deterioration reported

The building-specific public record reports recurring heat and hot-water problems, elevator-related complaints, and September 2026 issues involving defective doors, garbage storage, bathroom ventilation, pests and paint/plaster. No building-specific published resident rating or written review was found that isolates Compass Six alone; the 3.7/5 rating reported above is for the broader Compass Residences cluster, so these physical-condition records should be treated as operational evidence rather than a resident-review score.

Published resident excerpts are mixed: one reviewer praised a “clean environment,” private courtyard, gym and “sweet” staff, but another reported an unlocked lobby, loud backyard parties, police activity and unanswered calls and emails. The building’s published materials list an on-site resident manager, security cameras, laundry, bike storage and outdoor recreation, while the review evidence does not establish that those services are consistently delivered.

300 HuntingtonGowanus/Carroll Gardens, New York
4.8/ 10
—/ 10
—/ 10

No applicable platform-level building rating was located, so the score uses the five individually read published comments. Two were positive, two negative, and one mixed/neutral; applying the prose-only share curve gives a provisional 4.8/10, with substantial uncertainty because these are public project-commentary posts rather than resident reviews.

+ All-electric building+ Energy-recovery ventilation+ Two passenger/freight elevators+ Green roof+ Waterfront stormwater planters
− Appearance described as “super meh”− One commenter questioned whether it was passively built
+ Waterfront esplanade+ Landscaping praised+ Canal setting praised+ Flexible outdoor seating+ Public park and community amenities

Published project reporting describes a fully electric building with energy-recovery ventilation, two 4,000-pound passenger/freight elevators, a green roof, and terraced stormwater planters. The only directly observed physical-condition commentary was aesthetic rather than a defect report: one commenter said, “Building is super meh,” while another questioned, “is it passive built?”

The available published commentary emphasizes the outdoor experience rather than resident operations: one commenter said, “Landscaping is great!” and another described the landscaping as “very okay” while adding, “LOVE IT.” No reviewed source located for this report supplied recurring complaints about management speed, staff attitude, security, or upkeep.

Only buildings that have reached handover are rated. 7 of 9 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
MONADNOCK DEVELOPMENT LLC
Headquarters
300 Huntington Street, Brooklyn, US
Gowanus · 11231
Founded
2006
Brooklyn, US
Entity type
PRIVATE
Revenue
not published
Business model
mixed use, masterplan, other

Partners

6 partners
Community Preservation Corporation
joint venture

Manhattan Bundle affordable rehabilitation partnership

Community Development Trust
funder

Manhattan Bundle affordable rehabilitation partnership

Christian Cultural Center
landowner

Innovative Urban Village master plan partnership

Gotham Organization
joint venture

Innovative Urban Village master plan partnership

Related Companies
joint venture

Hunter’s Point South first two buildings

Phipps Houses
joint venture

Hunter’s Point South first two buildings

Sources: name

COMPANY2021-07-14

NYCHA - Manhattan Bundle - Monadnock Development

Monadnock Development
The Manhattan Bundle is an affordable rehabilitation project developed by Monadnock in partnership with the Community Preservation Corporation (CPC), the Community Development Trust (CDT), Kalel Holdings and Lemor Development Group.
value seen: Community Preservation Corporation
https://monadnockdevelopment.com/project/nycha/

Sources: summary

COMPANY2021-07-14

NYCHA - Manhattan Bundle - Monadnock Development

Monadnock Development
The Manhattan Bundle is an affordable rehabilitation project developed by Monadnock in partnership with the Community Preservation Corporation (CPC)
value seen: Manhattan Bundle affordable rehabilitation partnership
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/nycha/

Sources: name

COMPANY2021-07-14

NYCHA - Manhattan Bundle - Monadnock Development

Monadnock Development
developed by Monadnock in partnership with the Community Preservation Corporation (CPC), the Community Development Trust (CDT), Kalel Holdings and Lemor Development Group.
value seen: Community Development Trust
https://monadnockdevelopment.com/project/nycha/

Sources: summary

COMPANY2021-07-14

NYCHA - Manhattan Bundle - Monadnock Development

Monadnock Development
The Manhattan Bundle is an affordable rehabilitation project developed by Monadnock in partnership with the Community Preservation Corporation (CPC), the Community Development Trust (CDT), Kalel Holdings and Lemor Development Group.
value seen: Manhattan Bundle affordable rehabilitation partnership
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/nycha/

Sources: name

COMPANY2024-03-29

Innovative Urban Village - Monadnock Development

Monadnock Development
Developed in partnership with the Christian Cultural Center and the Gotham Organization.
value seen: Christian Cultural Center
https://monadnockdevelopment.com/project/3328/

Sources: summary

COMPANY2024-03-29

Innovative Urban Village - Monadnock Development

Monadnock Development
Developed in partnership with the Christian Cultural Center and the Gotham Organization.
value seen: Innovative Urban Village master plan partnership
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/3328/

Sources: name

COMPANY2024-03-29

Innovative Urban Village - Monadnock Development

Monadnock Development
Developed in partnership with the Christian Cultural Center and the Gotham Organization.
value seen: Gotham Organization
https://monadnockdevelopment.com/project/3328/

Sources: summary

COMPANY2024-03-29

Innovative Urban Village - Monadnock Development

Monadnock Development
Developed in partnership with the Christian Cultural Center and the Gotham Organization.
value seen: Innovative Urban Village master plan partnership
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/3328/

Sources: name

COMPANY2020-07-13

Hunter's Point South - Hacked by FroggBaba

Monadnock Development
In 2010, Monadnock and its development partners at the Related Companies and Phipps Houses were selected to develop the first two buildings in New York’s next great neighborhood
value seen: Related Companies
https://monadnockdevelopment.com/project/hunters-point-south/

Sources: summary

COMPANY2020-07-13

Hunter's Point South - Hacked by FroggBaba

Monadnock Development
Monadnock and its development partners at the Related Companies and Phipps Houses were selected to develop the first two buildings
value seen: Hunter’s Point South first two buildings
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/hunters-point-south/

Sources: name

COMPANY2020-07-13

Hunter's Point South - Hacked by FroggBaba

Monadnock Development
Monadnock and its development partners at the Related Companies and Phipps Houses were selected to develop the first two buildings
value seen: Phipps Houses
https://monadnockdevelopment.com/project/hunters-point-south/

Sources: summary

COMPANY2020-07-13

Hunter's Point South - Hacked by FroggBaba

Monadnock Development
Monadnock and its development partners at the Related Companies and Phipps Houses were selected to develop the first two buildings
value seen: Hunter’s Point South first two buildings
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/project/hunters-point-south/

Registrations & licences

COMPANY NUMBER5584926
New York Department of State · US · Active
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries
United Statesactive 9 projects tracked

What they build

5 types
Residential, for rent8 of 9
Retail2 of 9
Mixed use2 of 9
Other1 of 9
Office1 of 9
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
NL
Nick Lembo
Nick Lembo founded Monadnock Construction and established Monadnock Development, where he remains involved in strategic guidance. His track record includes founding The Hudson Companies and Capsys Corp.; the latter delivered more than 3 million square feet of modular housing and hotels.
Current title
Founder and Chairman; Of Counsel
Experience
no career length stated
Companies before
The Hudson CompaniesCapsys Corp.
Education
Cornell UniversityBachelor of Architecture
Other boards
Boards of several nonprofit organizations
Known for
FounderChairmanCornell architectureFounded CapsysAffordable housing
since Monadnock Development was established in 2005
much-needed, high-quality housing across New York City. Commercial Observer December 2, 2025https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/

Sources: degree

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
He received a Bachelor of Architecture degree from Cornell University and in 1975, he founded Monadnock Construction.
value seen: Bachelor of Architecture degree
https://monadnockdevelopment.com/company/

Sources: institution

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
He received a Bachelor of Architecture degree from Cornell University and in 1975, he founded Monadnock Construction.
value seen: Cornell University
https://monadnockdevelopment.com/company/

Sources: other boards

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
A past president of the Associated General Contractors of New York State, Nick continues to serve on the boards of several nonprofit organizations.
value seen: boards of several nonprofit organizations
value paraphrased from this source
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/

Sources: previous companies

PRESS2018-02-22

DSS Wrap-up: Nick Lembo and Kirk Goodrich of Monadnock (4 mins) – Cornell Real Estate Review

Cornell Real Estate Review
Nick went on to found three other companies over the next three decades: The Hudson Companies, a real estate development firm; Capsys Corp., a modular building manufacturer; and Monadnock Development, a development company formed once he exited Hudson.
value seen: The Hudson Companies; Capsys Corp.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://blog.realestate.cornell.edu/2018/02/22/dss-wrap-up-monadnock/

Sources: date

PRESS2025-12-02

PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development

Commercial Observer
By Brian Pascus December 2, 2025 12:14 pm
value seen: December 2, 2025
https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/

Sources: publisher

PRESS2025-12-02

PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development

Commercial Observer
# PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development
value seen: Commercial Observer
held out of the figures · the quote does not carry this value
https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/

Sources: quote

PRESS2025-12-02

PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development

Commercial Observer
Nick Lembo, founder and chairman of Monadnock Development, said in a statement that the project at 155 Third Street creates “much-needed, high-quality housing across New York City.”
value seen: much-needed, high-quality housing across New York City.
https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/

Sources: role type

PRESS2025-12-02

PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development

Commercial Observer
Nick Lembo, founder and chairman of Monadnock Development, said in a statement that the project at 155 Third Street creates “much-needed, high-quality housing across New York City.”
value seen: founder and chairman
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/

Sources: since

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
Nick established Monadnock Development in 2005, which has since developed more than 11,000 apartments and homes across the region, including affordable and market-rate, for-sale and rental properties.
value seen: Nick established Monadnock Development in 2005
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/

Sources: summary

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
Nick established Monadnock Development in 2005, which has since developed more than 11,000 apartments and homes across the region, including affordable and market-rate, for-sale and rental properties.
value seen: established Monadnock Development in 2005
value paraphrased from this source
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/

Sources: tags

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
The founder of Monadnock, Nick Lembo remains active in strategic planning and advising on Monadnock’s construction and development operations.
value seen: The founder of Monadnock
value paraphrased from this source
https://monadnockdevelopment.com/company/
COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Nick was born and raised in Brooklyn. He received a Bachelor of Architecture degree from Cornell University and in 1975, he founded Monadnock Construction.
value seen: Bachelor of Architecture degree from Cornell University
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: title

PRESS2025-12-02

PCCP, US Bank Provide $175M Financing for Brooklyn Multifamily Development

Commercial Observer
Nick Lembo, founder and chairman of Monadnock Development, said in a statement that the project at 155 Third Street creates “much-needed, high-quality housing across New York City.”
value seen: founder and chairman of Monadnock Development
https://commercialobserver.com/2025/12/pccp-boa-175m-financing-brooklyn-multifamily-development/
KG
Kirk Goodrich
Kirk Goodrich is President of Monadnock Development and leads its development platform. He previously led Enterprise Community Investment’s housing-tax-credit syndication business, where his team financed 12,000 affordable units and invested approximately $1 billion, and he has more than 30 years in community development and housing finance.
Current title
President
since Jul 2010 - Present
Experience
30+ years real estate
Companies before
Enterprise Community InvestmentRedevelopment Authority of Philadelphia
Education
Fordham UniversityJuris Doctorate
University of Illinois Urbana-ChampaignMaster of Urban Planning
Cornell UniversityBachelor of Science
Other boards
Chairman, New York State Association for Affordable Housing (NYSAFAH)Executive committee, Citizens Housing & Planning CouncilBoard, Metro Industrial Areas Foundation Community Restoration Fund
Known for
Presidentex-EnterpriseAffordable housing financeNYSAFAH ChairCornell
https://www.linkedin.com/in/kirkgoodrichaffordablehousing

Sources: education

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Kirk received a juris doctorate degree from Fordham University, a master of urban planning from the University of Illinois Urbana-Champaign, and a bachelor of science from Cornell University.
value seen: juris doctorate degree from Fordham University, a master of urban planning from the University of Illinois Urbana-Champaign, and a bachelor of science from Cornell University
https://monadnockdevelopment.com/company/

Sources: full name

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Kirk Goodrich serves as the President of Monadnock Development
value seen: Kirk Goodrich
https://monadnockdevelopment.com/company/

Sources: linkedin page

SOCIAL2026-09-25

kirk goodrich

LinkedIn
# kirk goodrich Partner, Monadnock Development
value seen: https://www.linkedin.com/in/kirkgoodrichaffordablehousing
value paraphrased from this source
https://www.linkedin.com/in/kirkgoodrichaffordablehousing

Sources: other boards

OTHERdate not shown in source

Document1

Enterprise Community Partners
Kirk has been Chairman of the New York State Association for Affordable Housing (NYSAFAH) since June 2019. He serves on the executive committee of Citizens Housing & Planning Council (CHPC) and on the board of the Metro Industrial Area Foundation Community Restoration Fund.
value seen: Chairman of the New York State Association for Affordable Housing (NYSAFAH); executive committee of Citizens Housing & Planning Council; board of the Metro Industrial Areas Foundation Community Restoration Fund
held out of the figures · the quote does not carry this value
https://www.enterprisecommunity.org/sites/default/files/2022-10/Kirk%20Goodrich.pdf

Sources: previous companies

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Prior to arriving at Enterprise in 1998, Kirk worked as a project manager for the Redevelopment Authority of Philadelphia handling property disposition and underwriting homeownership developments such as West Poplar Nehemiah, in North Philadelphia east of Broad Street.
value seen: Enterprise Community Investment; Redevelopment Authority of Philadelphia
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: date

PRESS2025-02-25

ULI New York: Success Strategies for Black Professionals in Real Estate

Urban Land Magazine
By Bendix Anderson February 25, 2025
value seen: February 25, 2025
https://urbanland.uli.org/issues-trends/celebrating-black-history-highlighting-success-stories-and-opportunities-in-nyc-commercial-real-estate

Sources: quote

PRESS2025-02-25

ULI New York: Success Strategies for Black Professionals in Real Estate

Urban Land Magazine
“Opportunities are scarce,” said Kirk Goodrich, president of Monadnock Development, based in Brooklyn.
value seen: Opportunities are scarce
https://urbanland.uli.org/issues-trends/celebrating-black-history-highlighting-success-stories-and-opportunities-in-nyc-commercial-real-estate

Sources: date

PRESS2025-02-25

ULI New York: Success Strategies for Black Professionals in Real Estate

Urban Land Magazine
By Bendix Anderson February 25, 2025
value seen: February 25, 2025
https://urbanland.uli.org/issues-trends/celebrating-black-history-highlighting-success-stories-and-opportunities-in-nyc-commercial-real-estate

Sources: quote

PRESS2025-02-25

ULI New York: Success Strategies for Black Professionals in Real Estate

Urban Land Magazine
“Diversity is not a favor,” Goodrich said.
value seen: Diversity is not a favor
https://urbanland.uli.org/issues-trends/celebrating-black-history-highlighting-success-stories-and-opportunities-in-nyc-commercial-real-estate

Sources: role type

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Kirk Goodrich serves as the President of Monadnock Development and has more than 30 years of experience in the fields of community development, affordable housing finance and real estate development.
value seen: President
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: since

SOCIAL2026-09-25

kirk goodrich

LinkedIn
Partner - Monadnock Development (Current) Jul 2010 - Present
value seen: Jul 2010 - Present
https://www.linkedin.com/in/kirkgoodrichaffordablehousing

Sources: summary

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
During that period, his team financed 12,000 units of affordable housing and invested approximately $1 billion.
value seen: his team financed 12,000 units of affordable housing and invested approximately $1 billion
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: tags

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Kirk Goodrich serves as the President of Monadnock Development and has more than 30 years of experience in the fields of community development, affordable housing finance and real estate development.
value seen: more than 30 years of experience
value paraphrased from this source
https://monadnockdevelopment.com/company/
COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
From 1998 to 2008,Kirk led the housing tax credit syndication business for Enterprise Community Investment - first in New York City and then in the northeast region.
value seen: From 1998 to 2008,Kirk led the housing tax credit syndication business for Enterprise Community Investment
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: title

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Kirk Goodrich serves as the President of Monadnock Development and has more than 30 years of experience in the fields of community development, affordable housing finance and real estate development.
value seen: President of Monadnock Development
https://monadnockdevelopment.com/company/
JP
Jens Peter Hansen
Peter Hansen remains Of Counsel to Monadnock Development and its affiliated construction company, providing strategic guidance and continuity. He joined Monadnock in 1984 after work as a residential contractor, with an architectural firm and a nonprofit housing organization, and has advised on operational issues and major multifamily projects.
Current title
Of Counsel; formerly Vice Chairman and Principal
since 1984
Experience
no career length stated
Companies before
none sourced
Education
Georgia Institute of TechnologyArchitecture
Other boards
Board of Directors, Brooklyn Community Housing and Services
Known for
Of CounselFormer Vice ChairmanPrincipalJoined 1984Architecture

Sources: education

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Peter studied architecture at the Georgia Institute of Technology.
value seen: Peter studied architecture at the Georgia Institute of Technology
https://monadnockdevelopment.com/company/

Sources: full name

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Peter Hansen is a Vice Chairman and Principal at Monadnock Construction.
value seen: Peter Hansen
https://monadnockdevelopment.com/company/

Sources: other boards

OTHERdate not shown in source

Leadership - Brooklyn Community Housing and Services

Brooklyn Community Housing and Services · carried by bchands.org
Jens Peter Hansen Monadnock Construction, Inc.
value seen: Jens Peter Hansen Monadnock Construction, Inc.
https://bchands.org/leadership/

Sources: role type

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
Nick Lembo and Peter Hansen remain “Of Counsel” to both companies, offering strategic guidance and continuity rooted in decades of experience.
value seen: Of Counsel
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/

Sources: since

PRESS2015-04-24

Monadnock Announces New President and Partners - Multi-Housing News

Multi-Housing News
Hansen is a partner in the firm and has served as vice-president for many years after joining the company as a superintendent in 1984.
value seen: joining the company as a superintendent in 1984
value paraphrased from this source
https://www.multihousingnews.com/monadnock-announces-new-president-and-partners/

Sources: summary

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
Nick Lembo and Peter Hansen remain “Of Counsel” to both companies, offering strategic guidance and continuity rooted in decades of experience.
value seen: remain “Of Counsel” to both companies, offering strategic guidance and continuity rooted in decades of experience
value paraphrased from this source
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/

Sources: tags

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Peter Hansen is a Vice Chairman and Principal at Monadnock Construction.
value seen: Vice Chairman and Principal
https://monadnockdevelopment.com/company/
COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Prior to joining Monadnock in 1984, Peter Hansen was a residential contractor and worked for an architectural firm and a not-for-profit housing organization.
value seen: Prior to joining Monadnock in 1984
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: title

PRESS2025-09-30

Raises $2.3 Million at 2025 Bishop's Dinner Event

Catholic Charities of Brooklyn & Queens · carried by ccbq.org
Nick Lembo and Peter Hansen remain “Of Counsel” to both companies, offering strategic guidance and continuity rooted in decades of experience.
value seen: Of Counsel
https://www.ccbq.org/catholic-charities-brooklyn-and-queens-raises-2-3-million-at-2025-bishops-humanitarian-dinner/
GB
Greg Bauso
Greg Bauso is a managing member and principal associated with Monadnock’s operating platform; he is President of Monadnock Construction. He joined in 1998 as a project manager, became a partner in 2002, and has overseen projects including Riverwalk, Courtlandt Corners and Hunters Point South’s first phase.
Current title
Managing Member; Principal and President of Monadnock Construction
since 2002
Experience
no career length stated
Companies before
none sourced
Education
not published
Other boards
none sourced
Known for
Managing MemberPrincipalPresidentPartner since 2002Operations

Sources: full name

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Greg is a principal of Monadnock and as President oversees all day-to-day aspects and functions of the construction company.
value seen: Greg Bauso
held out of the figures · the quote does not carry this value
https://monadnockdevelopment.com/company/

Sources: role type

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Greg is a principal of Monadnock and as President oversees all day-to-day aspects and functions of the construction company.
value seen: principal and President oversees all day-to-day aspects
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: since

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
After successfully completing multiple projects for Monadnock, Greg became a partner in the company during 2002.
value seen: became a partner in the company during 2002
https://monadnockdevelopment.com/company/

Sources: summary

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Significant projects undertaken during that period and overseen by Greg include the multi-building Riverwalk project on Roosevelt Island, the Courtlandt Corners project in the Bronx, and the first phase of the Hunters Point South middle-income housing development in Long Island City.
value seen: Significant projects undertaken during that period and overseen by Greg include the multi-building Riverwalk project on Roosevelt Island, the Courtlandt Corners project in the Bronx, and the first phase of the Hunters Point South middle-income housing development in Long Island City
https://monadnockdevelopment.com/company/

Sources: tags

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Greg is a principal of Monadnock and as President oversees all day-to-day aspects and functions of the construction company.
value seen: principal of Monadnock
https://monadnockdevelopment.com/company/
COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
After successfully completing multiple projects for Monadnock, Greg became a partner in the company during 2002.
value seen: became a partner in the company during 2002
https://monadnockdevelopment.com/company/
COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Greg is a principal of Monadnock and as President oversees all day-to-day aspects and functions of the construction company.
value seen: oversees all day-to-day aspects and functions
https://monadnockdevelopment.com/company/

Sources: title

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Greg is a principal of Monadnock and as President oversees all day-to-day aspects and functions of the construction company.
value seen: Managing Member; Principal and President
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://monadnockdevelopment.com/company/
FD
Frank Dubinsky
Frank Dubinsky is Chief Operating Officer of Monadnock Development and leads its development team through preconstruction and construction. His background includes nearly two decades of affordable-housing development and financing, with projects spanning mixed-income, mixed-use, rental, cooperative and waterfront developments.
Current title
Chief Operating Officer
Experience
20+ years housing
Companies before
none sourced
Education
Stanford UniversityBachelor’s degree in Urban Studies, concentration in Architecture and Urban Design
Other boards
none sourced
Known for
COOLeads development teamMixed-useStanfordAffordable housing
The key is to triangulate the uses that the neighborhood and our residents want with what is financially feasible. Commercial Search May 23, 2024https://www.commercialsearch.com/news/why-mixed-use-developments-are-all-about-the-right-synergies/
Co-locating in close proximity to our tenants and future occupants allows Monadnock the ability to continue our mission and reputation as providers of best-in-class real estate solutions to the community. New York Real Estate Journal November 14, 2023https://nyrej.com/monadnock-development-starts-leasing-for-136-000-s-f-mixed-use-building

Sources: education

OTHERdate not shown in source

CFMA NYC + NYCSA: New York Region Developer Panel - Construction Financial Management Association

Construction Financial Management Association · carried by cenohio.cfma.org
He has a bachelor’s degree from Stanford University in Urban Studies with a Concentration in Architecture and Urban Design.
value seen: bachelor’s degree from Stanford University in Urban Studies with a Concentration in Architecture and Urban Design
https://cenohio.cfma.org/events/details/cfma-nyc-and-nycsa-new-york-region-developer-panel-4327

Sources: full name

OTHER2023-08-15

Frank Dubinsky - Van Alen Institute

Van Alen Institute · carried by vanalen.org
### Chief Operating Officer, Monadnock Development
value seen: Frank Dubinsky
held out of the figures · the quote does not carry this value
https://www.vanalen.org/person/frank-dubinsky/

Sources: date

PRESS2024-05-23

Why Mixed-Use Developments Are All About the Right Synergies

Commercial Search
By Adina Rogoz • May 23, 2024
value seen: May 23, 2024
https://www.commercialsearch.com/news/why-mixed-use-developments-are-all-about-the-right-synergies/

Sources: publisher

PRESS2024-05-23

Why Mixed-Use Developments Are All About the Right Synergies

Commercial Search
# Why Mixed-Use Developments Are All About the Right Synergies
value seen: Commercial Search
held out of the figures · the quote does not carry this value
https://www.commercialsearch.com/news/why-mixed-use-developments-are-all-about-the-right-synergies/

Sources: quote

PRESS2024-05-23

Why Mixed-Use Developments Are All About the Right Synergies

Commercial Search
Dubinsky: The key is to triangulate the uses that the neighborhood and our residents want with what is financially feasible.
value seen: The key is to triangulate the uses that the neighborhood and our residents want with what is financially feasible.
https://www.commercialsearch.com/news/why-mixed-use-developments-are-all-about-the-right-synergies/

Sources: date

PRESS2023-11-14

Monadnock Development starts leasing for 136,000 s/f mixed-use building 300 Huntington

New York Real Estate Journal
Posted: November 14, 2023
value seen: November 14, 2023
https://nyrej.com/monadnock-development-starts-leasing-for-136-000-s-f-mixed-use-building

Sources: publisher

PRESS2023-11-14

Monadnock Development starts leasing for 136,000 s/f mixed-use building 300 Huntington

New York Real Estate Journal
# Monadnock Development starts leasing for 136,000 s/f mixed-use building 300 Huntington
value seen: New York Real Estate Journal
held out of the figures · the quote does not carry this value
https://nyrej.com/monadnock-development-starts-leasing-for-136-000-s-f-mixed-use-building

Sources: quote

PRESS2023-11-14

Monadnock Development starts leasing for 136,000 s/f mixed-use building 300 Huntington

New York Real Estate Journal
“Co-locating in close proximity to our tenants and future occupants allows Monadnock the ability to continue our mission and reputation as providers of best-in-class real estate solutions to the community.”
value seen: Co-locating in close proximity to our tenants and future occupants allows Monadnock the ability to continue our mission and reputation as providers of best-in-class real estate solutions to the community.
https://nyrej.com/monadnock-development-starts-leasing-for-136-000-s-f-mixed-use-building

Sources: role type

OTHER2023-08-15

Frank Dubinsky - Van Alen Institute

Van Alen Institute · carried by vanalen.org
### Chief Operating Officer, Monadnock Development
value seen: Chief Operating Officer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.vanalen.org/person/frank-dubinsky/

Sources: summary

OTHER2023-08-15

Frank Dubinsky - Van Alen Institute

Van Alen Institute · carried by vanalen.org
Frank leads the development team and oversees the company’s developments in preconstruction and construction.
value seen: Frank leads the development team and oversees the company’s developments in preconstruction and construction
https://www.vanalen.org/person/frank-dubinsky/

Sources: tags

OTHER2023-08-15

Frank Dubinsky - Van Alen Institute

Van Alen Institute · carried by vanalen.org
Frank Dubinsky is closing in on two decades of work developing and financing affordable housing.
value seen: closing in on two decades of work developing and financing affordable housing
value paraphrased from this source
https://www.vanalen.org/person/frank-dubinsky/

Sources: title

OTHER2023-08-15

Frank Dubinsky - Van Alen Institute

Van Alen Institute · carried by vanalen.org
### Chief Operating Officer, Monadnock Development
value seen: Chief Operating Officer, Monadnock Development
https://www.vanalen.org/person/frank-dubinsky/
AL
Alphonse Lembo
Alphonse Lembo is a partner and principal of Monadnock Development and directs preconstruction for the affiliated construction business. He joined Monadnock in 2010 after earlier work at Forsyth Street Advisors and JES Plumbing and Heating, became Director of Preconstruction in 2016, and serves on the NYC Outward Bound Schools board.
Current title
Partner; Principal; Director of Preconstruction
since 2016
Experience
no career length stated
Companies before
Forsyth Street AdvisorsJES Plumbing and Heating
Education
Stuyvesant High SchoolDiploma
The University of ChicagoBachelor of Arts with honors
Harvard UniversityMaster of Urban Planning
Other boards
Board, NYC Outward Bound Schools
Known for
PartnerPrincipalDirector of PreconstructionUniversity of ChicagoHarvard MUP
https://www.linkedin.com/in/alphonse-lembo

Sources: education

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Alphonse received a Diploma from Stuyvesant High School, a Bachelor of Arts with honors from The University of Chicago, and a Master of Urban Planning degree from Harvard University (with a concentration in Real Estate Development and Finance).
value seen: Diploma from Stuyvesant High School, a Bachelor of Arts with honors from The University of Chicago, and a Master of Urban Planning degree from Harvard University
https://monadnockdevelopment.com/company/

Sources: full name

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Alphonse Lembo is a principal of both Monadnock Construction, Inc. ... and of Monadnock Development LLC.
value seen: Alphonse Lembo
https://monadnockdevelopment.com/company/

Sources: other boards

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
He serves on the board of NYC Outward Bound Schools.
value seen: board of NYC Outward Bound Schools
https://monadnockdevelopment.com/company/

Sources: previous companies

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Prior to Monadnock he worked at Forsyth Street Advisors and JES Plumbing and Heating.
value seen: Forsyth Street Advisors and JES Plumbing and Heating
https://monadnockdevelopment.com/company/

Sources: role type

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Alphonse Lembo is a principal of both Monadnock Construction, Inc., for which he directs all Preconstruction activities, and of Monadnock Development LLC.
value seen: directs all Preconstruction activities
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://monadnockdevelopment.com/company/

Sources: since

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
In 2016, he became Monadnock’s Director of Preconstruction.
value seen: In 2016, he became Monadnock’s Director of Preconstruction
https://monadnockdevelopment.com/company/

Sources: summary

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Alphonse joined Monadnock in 2010 as an Assistant Project Manager after having worked part-time as a laborer during his summer breaks from school. In 2016, he became Monadnock’s Director of Preconstruction.
value seen: joined Monadnock in 2010 as an Assistant Project Manager; in 2016, he became Monadnock’s Director of Preconstruction
https://monadnockdevelopment.com/company/

Sources: tags

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
He is a LEED AP and PHIUS+ Certified Passive House Consultant (CPHC).
value seen: LEED AP and PHIUS+ Certified Passive House Consultant (CPHC)
https://monadnockdevelopment.com/company/

Sources: title

COMPANYdate not shown in source

Company - Monadnockdevelopment

Monadnock Development
Alphonse Lembo is a principal of both Monadnock Construction, Inc., for which he directs all Preconstruction activities, and of Monadnock Development LLC.
value seen: principal of both Monadnock Construction, Inc. and Monadnock Development LLC; Director of Preconstruction
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://monadnockdevelopment.com/company/

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 1 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases
The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

9 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
Sarah Plowden PlaceNew York, United States
East New York
residential for rent18418—USD 135.9m
other
————Sep 2026—not scorablecompleted
Utica CrescentNew York, United States
East Flatbush
residential for rent, retail, mixed use322112 stories—USD 256m
construction loan
———Jun 2026Jun 20260.0 mo
(0.0 to 0.0)
estimatedcompleted
Nehemiah Spring Creek Phase 4CNew York, United States
Brooklyn
residential for rent2401————2022December 2022May 2024 – Aug 2024Jan 2025 – Dec 2025+12.0 mo
(+5.0 to +19.0)
sourcedcompleted
NYCHA - Manhattan BundleNew York, United States
Manhattan
residential for rent, other1,7181—1,937,000 sq ftUSD 383m
other
—2019June 21, 2019May 2023 – Aug 2023Jun 2024+11.5 mo
(+10.0 to +13.0)
estimatedcompleted
300 HuntingtonNew York, United States
Gowanus/Carroll Gardens
office, retail, mixed use—six-story136,000 sq ft————Jan 2023 – Dec 2023Jan 2024 – Dec 2024+12.0 mo
(+1.0 to +23.0)
estimatedcompleted
Compass Six ResidencesNew York, United States
Crotona Park East and West Farms
residential for rent261116232,145 sq ft——2021Mar 19, 2021Jan 2024 – Dec 2024May 2023more than 9 months earlyestimatedcompleted
Nehemiah Spring Creek Phase 4B-2New York, United States
Brooklyn
residential for rent2401————2020November 9, 2020—Jan 2022 – Dec 2022—not scorablecompleted
Compass Residences Phase 3New York, United States
Crotona Park East/West Farms
residential for rent3661—356,000 sq ft————Dec 2019Feb 2020+2.0 mo
(+2.0 to +2.0)
sourcedcompleted
Nehemiah Spring Creek Phase 4B-1New York, United States
residential for rent1601———————Jan 2020 – Dec 2020—not scorablecompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

4 found
COMPANY AWARD Winner 2021 (announced June 22, 2021)
Visionary Leadership in Land Use Award
The award recognized Kirk Goodrich, president of Monadnock Development, for a body of work and civic engagement described as having a transformational impact on New York’s real-estate community and industry.
PROJECT AWARD Winner 2020 (winners announced November 2, 2020; reported December 1, 2020)
Excellence in Affordable Housing Development · One Flushing
One Flushing won ULI New York’s Excellence in Affordable Housing Development award; the winning development team included Asian Americans for Equality, HANAC, and Monadnock Development.
GOVERNMENT RECOGNITION Winner 2018
Big Apple Brownfield Award for Environmental Protection · One Flushing
One Flushing received the 2018 Big Apple Brownfield Award for Environmental Protection; the source identifies Monadnock Development, Asian Americans for Equality, and HANAC as the developers and describes the site’s brownfield remediation and unrestricted-use cleanup.
PROJECT AWARD Winner 2017
AIA National Institute Honor Award · Carmel Place
Carmel Place, whose client and developer listing identifies Monadnock Development, received the 2017 AIA National Institute Honor Award.
American Institute of Architects · https://narchitects.com/work/carmel-place/

Risks

Risk flags

5 found
SAFETY / LABOUR Filed January 15, 2026; docket remained open through May 18, 2026
A civil labor-and-employment lawsuit was filed against Monadnock Development LLC in Kings County Supreme Court; the publicly available docket identifies the case as open as of the latest docket entries, but does not state the underlying allegations or any adjudicated outcome.
LEGAL Filed January 25, 2024; partial discontinuance recorded December 4, 2025
Monadnock Development LLC and related project entities sued Capitol Specialty Insurance Corporation and another insurer in a coverage dispute; the case was reported as open, with a partial discontinuance recorded on December 4, 2025, and no final merits outcome established by the retrieved docket.
LEGAL Injury July 16, 2022; court decision April 8, 2026
In litigation arising from a July 16, 2022 construction-site injury, Monadnock Development LLC was a plaintiff seeking insurance defense and indemnification; the court’s April 8, 2026 decision denied the insurer’s motion to add counterclaims, while the underlying coverage motions remained undecided.
DELIVERY DELAY April 25, 2024 (publication and reported status)
155 Third Street in Gowanus, Brooklyn—developed by Monadnock Development—was stalled by the 421-a deadline and financing uncertainty; Monadnock’s COO said in April 2024 that the project had been infeasible to complete by the then-applicable deadline but was moving forward again after the deadline extension, so this is a documented resolved/restarted delay rather than evidence of current abandonment.
DELIVERY DELAY August 31, 2015 (publication and reported status; outside the rolling window, retained as older unresolved-material-failure evidence)
The broader Nehemiah Spring Creek affordable-housing development in East New York, involving Monadnock Construction with Nehemiah and Metro IAF, was reported in 2015 as languishing: only 300 of 1,803 planned affordable units had come online and city infrastructure was projected for late 2017; this is older evidence of material delay, not proof that the entire development remains stalled as of October 15, 2026.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 15, 2026 this month
Profile last researchedOctober 15, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.