Artificial Intelligence
Builders Company
Developers/Starwood Capital Group
SC
Starwood Capital GroupMiami Beach, United States · founded 1991 · 1 active markets
PRIVATE

Starwood Capital Group invests in and develops real estate and real assets globally, including residential, hospitality, multifamily, commercial, industrial, retail, office, land, and data-center projects, serving institutional and high-net-worth investors through opportunistic funds, affiliated platforms, and operating partnerships across markets.

Years in business
35
founded 1991
LinkedIn headcount
676
employees, as shown on LinkedIn · size band 1,001–5,000
Assets under management
USD 130 billion
Jul 01, 2026
Projects last researched October 14, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
STARWOOD CAPITAL GROUP MANAGEMENT, L.L.C.1
Headquarters
2340 Collins Avenue1, Miami Beach1, United States
Founded
19911
Entity type
PRIVATE1
Business model
offplan for sale1, commercial1, mixed use1, other1
Markets
1 market listed
What they build
Hotel (5 of 7) · Retail (2 of 7) · Mixed use (2 of 7)
Full dossier in About →

Delivery record

6 date-assessed of 7 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 1 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
7
within the rolling ten-year window
Median delay
+10.5 mo
the middle of 6 scored projects
Average delay
+10.8 mo
the same projects, pulled by the worst
Average time to deliver
3.7 yrs
start to completion, over 6 delivered projects
Worst slip
+16.0 mo
1 Hotel Brooklyn Bridge · +15.0 to +17.0
1
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
3
red rows below

Against other developers

6 date-assessed here · 255 developers, 954 date-assessed projects in United States
Median delay
Starwood Capital Group·255 developers in United States
+10.5 mo vs +4.5 mo
this developer 6.0 mo worse
The typical project on each side.
Average delay
Starwood Capital Group·255 developers in United States
+10.8 mo vs +7.4 mo
this developer 3.4 mo worse
Both pulled by their worst few.
On time
Starwood Capital Group·255 developers in United States
17% vs 56%
this developer 39 pts worse
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Starwood Capital Group·255 developers in United States
3.7 yrs vs 2.9 yrs
this developer 0.8 yrs slower
Start to completion, over 6 delivered here and 786 in the market.
Projects and timelines in Track Record →

Resident experience

6 of 7 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.3/ 10
Weighted judgment across build and operations · from 6 of 6 rated buildings
Structure & systems
7.5/ 10
Fabric, services, waterproofing, envelope · from 4 of 6 rated buildings
Management & living
7.5/ 10
Upkeep, response times, amenities, community · from 6 of 6 rated buildings

Against other developers

6 rated here · 276 developers, 1411 rated buildings in United States
Overall rating
Starwood Capital Group · 276 other developers in United States
8.3 vs 7.8
this developer 0.5 better
The weighted verdict on each side. From 6 of 6 rated buildings here and 1411 in the market.
Structure & systems
Starwood Capital Group · 276 other developers in United States
7.5 vs 6.9
this developer 0.6 better
Fabric and engineering only — fixed at handover. From 4 of 6 rated buildings here and 597 in the market.
Management & living
Starwood Capital Group · 276 other developers in United States
7.5 vs 7.4
this developer 0.1 better
Upkeep and response — belongs to whoever runs the building now. From 6 of 6 rated buildings here and 1356 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.
Ratings by building →

Awards & recognition

All awards →

Risks & source coverage

Record status
active
Company sources
127 source entries across 127 fields
Projects tracked
8 · 7 completed in assessment
All flags and sources →

Track Record

Delivery record

6 date-assessed of 7 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 1 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
7
within the rolling ten-year window
Median delay
+10.5 mo
the middle of 6 scored projects
Average delay
+10.8 mo
the same projects, pulled by the worst
Average time to deliver
3.7 yrs
start to completion, over 6 delivered projects
Worst slip
+16.0 mo
1 Hotel Brooklyn Bridge · +15.0 to +17.0
1
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
3
red rows below

Against other developers

6 date-assessed here · 255 developers, 954 date-assessed projects in United States
Median delay
Starwood Capital Group·255 developers in United States
+10.5 mo vs +4.5 mo
this developer 6.0 mo worse
The typical project on each side.
Average delay
Starwood Capital Group·255 developers in United States
+10.8 mo vs +7.4 mo
this developer 3.4 mo worse
Both pulled by their worst few.
On time
Starwood Capital Group·255 developers in United States
17% vs 56%
this developer 39 pts worse
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Starwood Capital Group·255 developers in United States
3.7 yrs vs 2.9 yrs
this developer 0.8 yrs slower
Start to completion, over 6 delivered here and 786 in the market.
The market here is United States: every other developer whose head office is in the same country, because planning regimes and reporting norms move together within one. It is not a city, a sector or a size band. Read the two delay figures together. A median close to the market with a much better average means no single disaster; the reverse means one project is carrying the record. Time to deliver runs from the earliest start we hold to the completion itself — a construction start where a source gave one, otherwise a sales launch, otherwise the launch year read as its January. A handover the sources place only inside a year is read as that December, so a duration is the widest the record allows rather than the flattering end of it. Only delivered projects dated at both ends count, so it is taken over fewer projects than the delay figures, and a long build is not a fault: a tower is not a villa run. Sourced figures only, both sides, and values taken from documents held on file are excluded here — a developer who shares their records should not score better than one who does not.

Construction start to handover

7 of 7 projects dated · 6 places
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
West Palm Beach, United States
United States
Nashville, United States
Miami Beach, United States
West Hollywood, United States
Brooklyn, United States
2012201320142015201620172018201920202021202220232024202520262027todayWEST PALM BEACH, UNITED STATES+5.5 moestimatedUNITED STATES+15 moverifiedNASHVILLE, UNITED STATES+8.5 moverified+7 moverifiedMIAMI BEACH, UNITED STATES+5.5 moverifiedWEST HOLLYWOOD, UNITED STATES+12.5 moverifiedBROOKLYN, UNITED STATES+16 moverified
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures. 1 turned out to be about something else — a phase, a neighbour, the wider masterplan — and is marked off-subject.

Building & Livability Ratings

Resident experience

6 of 7 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.3/ 10
Weighted judgment across build and operations · from 6 of 6 rated buildings
Structure & systems
7.5/ 10
Fabric, services, waterproofing, envelope · from 4 of 6 rated buildings
Management & living
7.5/ 10
Upkeep, response times, amenities, community · from 6 of 6 rated buildings

Against other developers

6 rated here · 276 developers, 1411 rated buildings in United States
Overall rating
Starwood Capital Group · 276 other developers in United States
8.3 vs 7.8
this developer 0.5 better
The weighted verdict on each side. From 6 of 6 rated buildings here and 1411 in the market.
Structure & systems
Starwood Capital Group · 276 other developers in United States
7.5 vs 6.9
this developer 0.6 better
Fabric and engineering only — fixed at handover. From 4 of 6 rated buildings here and 597 in the market.
Management & living
Starwood Capital Group · 276 other developers in United States
7.5 vs 7.4
this developer 0.1 better
Upkeep and response — belongs to whoever runs the building now. From 6 of 6 rated buildings here and 1356 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.

By building

6 rated · 1 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
1 Hotel NashvilleSoBro, Nashville215 units
9.0/ 10
8.6/ 10
Tripadvisor 4.7/5 · 671 reviews · tripadvisor.com
Roomer Travel 9.5/10 · 393 reviews · roomertravel.com
Combined from 2 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 8.6.
8.4/ 10
Tripadvisor 4.9/5, 4.6/5, 4.8/5, 4.8/5, 4.7/5 · 671 reviews · tripadvisor.com
Combined from 5 published figures on 1 platform, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 8.4.

Tripadvisor supplies the largest review base and its 4.8/5 overall rating converts to 9.4 under the stated curve. Expedia’s 9.2/10 and Google’s 4.6/5 broadly corroborate a very strong guest experience, while the reported minor complaints justify a modest reduction to 9.0 overall. Structure is supported by Tripadvisor’s room/cleanliness ratings and Roomer’s 9.5/10 maintenance score; living is supported by service, location, amenities and the guest aggregates.

+ High cleanliness+ Well-maintained bathrooms+ Comfortable rooms+ Strong property condition+ Premium bedding and fixtures
− Some bathroom dissatisfaction− Minor street/rooftop noise− No pool
+ Friendly and attentive staff+ Strong service+ Excellent location+ Spa and wellness amenities+ Rooftop bar and dining
− Parking cost concerns− Unexpected fees/value complaints− No pool− Rooftop/street noise− Small gym

Tripadvisor published 4.7/5 for rooms and 4.8/5 for cleanliness, while Roomer published 9.5/10 for cleanliness and maintenance, describing housekeeping as “immaculate” and bathrooms as “spotless.” The written reviews praise beautiful, comfortable rooms and sleep quality, but Google’s review-topic summary shows bathrooms at 65% unfavorable and rooms at 35% unfavorable, so the otherwise strong physical-condition picture is not uniformly positive.

Guests repeatedly describe staff as “friendly,” “helpful,” “polite and wonderful,” and praise the spa, restaurants, house car and walkable location. The main operational/value criticisms are paid parking and unexpected charges; one Tripadvisor reviewer also reported that the initial welcome was not friendly and said, “Wish they had a pool,” while Google’s summary shows parking at 59% unfavorable.

1 Hotel Brooklyn BridgeDUMBO, Brooklyn194 units
8.8/ 10
7.8/ 10
Tripadvisor 4.7/5 · 2,154 reviews · tripadvisor.com
Roomer Travel 8.5/10 · 373 reviews · roomertravel.com
Combined from 2 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.8.
6.4/ 10
Tripadvisor 4.8/5, 4.3/5, 4.7/5 · 2,154 reviews · tripadvisor.com
Roomer Travel 6.5/10 · 373 reviews · roomertravel.com
Combined from 4 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 6.4.

Google's 4.3/5 rating has the largest explicitly reported review base, so it sets the level at 7.9/10 under the supplied conversion curve. The score moves upward for repeated praise of staff, views, location and amenities, but recurring noise and operational/room complaints limit the uplift; structure is scored separately from the reported room-condition evidence and living from the management and amenity evidence.

+ Modern room design+ Generally clean rooms+ Comfortable beds and linens+ Well-kept furnishings
− Night-time traffic and rooftop noise− Occasional hot-water issue− Balcony-door/TV malfunctions− Thin walls− Bathroom privacy concerns
+ Warm, responsive staff+ Strong concierge and front-desk service+ Exceptional views and location+ Rooftop pool and amenities+ Cleanliness generally praised
− Night-time noise− High prices/value complaints− Occasional unresolved complaints− Crowded pool/common areas− Inconsistent housekeeping

Published guest feedback describes the rooms as “super cute and modern,” “well kept” and clean, and Tripadvisor reports 4.7/5 for rooms. The recent-review analysis nevertheless records 11 bathroom-problem reports, including “Shower would not run hot,” and eight reports of something broken in the room; another guest reported a balcony door that did not fully close and a malfunctioning TV.

Daily-life feedback is strongest on people and place: Tripadvisor guests say staff were “warm, gracious and genuinely invested,” while the recent-review analysis counts 152 staff praises versus 25 complaints and 120 view praises. The main operational drawbacks are noise—22 of 38 reviewers mentioning quiet at night complained—plus value concerns and isolated failures such as missing towels/toilet tissue, non-working Wi-Fi and dirty plates around the pool.

1 Hotel Hanalei BayPrinceville252 units
8.5/ 10
7.5/ 10
8.3/ 10
Tripadvisor 4.7/5, 4.9/5, 4.7/5, 4.5/5, 4.7/5, 4.7/5 · 690 reviews · tripadvisor.com
Combined from 6 published figures on 1 platform, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 8.3.

Tripadvisor’s 4.5/5 from 690 reviews is the largest directly reported review base and converts to 8.5 under the specified curve. Booking.com’s reported 9.1/10 is directionally consistent, while the written reviews support strong living quality but also document isolated room-condition and management failures.

− Apparent ceiling mold− Mildew odor− Unreliable shower pressure and temperature− Dark/inadequate room lighting
+ Exceptional views and setting+ Warm attentive staff+ Strong pools, beach and spa+ Beautiful grounds and design+ Prompt housekeeping reported
− High prices− Inconsistent management/service− Valet bottlenecks− Occasional activity and restaurant shortcomings− Limited room space for some families

One August 2026 review reported “what appeared to be mold” on the ceiling, a “very strong mildew smell,” and shower pressure and temperature that fluctuated; the reviewer said the response did not adequately resolve the concerns. Other reviews mention dark rooms and a shower head needing more regular cleaning, but no published engineering or building-condition assessment was found.

Guests repeatedly praise the setting, pools, beach, fitness and spa, with one calling the staff “warm, accommodating, and genuinely wonderful” and another describing the service during a hurricane as exceptionally caring. Counterevidence includes “painfully overpriced” services, a report of an unresponsive concierge and rude restaurant management, valet waits of “20-25 min,” and a reviewer saying the outrigger activity lacked enough employees to operate reliably.

Embassy Suites by Hilton Nashville DowntownSoBro, Nashville506 units
8.2/ 10
—/ 10
7.0/ 10
Tripadvisor 4.6/5, 4.8/5, 4.5/5 · 352 reviews · tripadvisor.com
KAYAK 10/10, 9.5/10, 8.5/10, 6/10, 1/10 · 963 reviews · kayak.com
Combined from 8 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.

Priceline has the largest published review base at 1,621 and sets the guest-rating anchor at 8.9/10, converted to 8.8 under the stated curve. Tripadvisor is materially lower, while the reported recurring operational problems justify a modest downward adjustment; there is no published structural evidence, so structure is unscored.

+ central location+ clean, modern rooms+ breakfast and evening reception+ friendly staff+ rooftop pool and bar
− elevator delays− slow or unresponsive service− high parking and added fees

no notes returned

no links returned

Guests repeatedly praise the location, cleanliness, breakfast and amenities: one recent review called the rooms “very clean” and employees “very welcoming,” while another praised the “Beautiful rooftop pool.” Operational feedback is mixed: reviewers report that only two of five elevators were working, a typical wait of at least 10 minutes, and that the front desk “NEVER” answered calls; KAYAK likewise publishes service at 6/10 and pool at 1/10.

LumaireDowntown West Palm Beach, West Palm Beach457 units
7.8/ 10
6.1/ 10
ApartmentRatings 3.3/5 · 14 reviews · apartmentratings.com
RentCafe 4.5/5 · 2 reviews · rentcafe.com
Combined from 2 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 6.1.
7.3/ 10
ApartmentRatings 4.2/5, 4.1/5, 3.7/5, 3.9/5, 4.4/5 · 14 reviews · apartmentratings.com
RentCafe 4/5, 5/5, 5/5, 4.5/5, 4.5/5, 5/5, 5/5 · 2 reviews · rentcafe.com
Combined from 12 published figures on 2 platforms, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.3.

Google's 4.6/5 from 149 reviews is the largest published review base and converts to an 8.8/10 anchor. The score is pulled down by multiple reports of prolonged AC outages, outages affecting power/internet, package failures and management responsiveness, with repeated positive reviews for cleanliness, staff, amenities and location limiting the reduction.

+ Modern, attractive building+ Common areas reported spotless+ Pool and fitness areas well maintained+ High-quality finishes reported by some residents
− Extended AC outages− Repeated power and internet outages− Appliance and temperature-control complaints− Elevator reliability complaints− Thin walls and train noise
+ Friendly professional staff+ Responsive management reported by some residents+ Strong pool, gym and amenity package+ Clean common areas+ Convenient downtown/Brightline access
− Inconsistent management responsiveness− Package-room disorder and missing packages− Reduced gym and coffee-machine availability− Internet disruptions− Train noise for some units

Residents variously describe Lumaire as “beautifully maintained” with “high-quality finishes,” but the infrastructure feedback is not uniform. Serious reports include a “4 week and counting Air Conditioning Outage” with indoor temperatures reaching 80 degrees, repeated power/internet outages, appliance failures and an elevator that “doesn't always work.”

Day-to-day experience is polarized: residents praise “friendly, professional” staff, spotless shared spaces, the pool and fitness facilities, while others report that management was “extremely difficult to work with,” packages went missing and internet outages disrupted work. The location is repeatedly praised, but train noise, reduced amenity hours and inconsistent maintenance follow-through temper the otherwise strong lifestyle feedback.

1 Hotel West HollywoodWest Hollywood, West Hollywood285 units
7.2/ 10
—/ 10
7.4/ 10
Booking.com 8.9/10, 9/10, 9.1/10, 9.1/10, 7.7/10, 9.2/10 · 659 reviews · booking.com
Combined from 6 published figures on 1 platform, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 7.4.

Booking.com’s building-specific guest aggregate of 8.6/10 from 659 reviews sets the level; under the specified guest-rating curve, 8.6 converts to 7.2/10. The written sample supports strong design, location, comfort and staff impressions but also recurring noise and smaller operational shortcomings, so no upward re-rating is warranted and structure remains unscored because no building-fabric rating was published.

+ Comfortable rooms and beds+ Clean and quiet rooms reported by some guests
− Noise and weak sound isolation− Clogged shower reported− Broken-glass housekeeping lapse
+ Helpful and welcoming staff+ Strong design and ambience+ Rooftop pool and spa appreciated+ Good location+ Comfortable beds and rooms
− Noise affects sleep− Pool shade and crowding− High prices/value concerns− Occasional slow or insufficient service− Rooftop/bar capacity constraints

Published guest feedback contains some physical-condition positives—one guest called the room “clean and quiet,” while another praised the “great shower pressure.” The negative infrastructure-related evidence is limited but concrete: Google shows “Shower was clogged,” Booking.com records a room as “very loud” with hallway and outside noise, and a Tripadvisor reviewer reported glass left in the carpet after a tray broke; these are review observations, not an engineering assessment.

The dominant lifestyle picture is attractive and service-oriented: guests praised the “chic vibe,” greenery, pool views, spa, location and “super helpful staff,” while Google’s summary says guests liked the service. Counterexamples include “very little staff at the front desk,” a “45 minutes” coffee wait, a rooftop that was “booked out all weekend,” and repeated comments that rooms were noisy; the available evidence is hotel-guest feedback rather than resident experience.

Only buildings that have reached handover are rated. 1 of 7 projects carries no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
STARWOOD CAPITAL GROUP MANAGEMENT, L.L.C.
Headquarters
2340 Collins Avenue, Miami Beach, United States
33139
Founded
1991
Entity type
PRIVATE
Revenue
not published
Business model
offplan for sale, commercial, mixed use, other

Offices

head office and 12 others
AtlantaChicagoAddisonGreenwichLos AngelesNew YorkSan FranciscoWashington, D.C.DubaiLondonLuxembourgJeonju

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Atlanta 400 Galleria Parkway, Suite 1450 Atlanta, GA 30339
value seen: Atlanta
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Chicago 222 N. LaSalle St., Suite 1935 Chicago, IL 60601
value seen: Chicago
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
2-4 rue Eugène Ruppert L-2453 Luxembourg
value seen: Luxembourg
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
Suite 503, 138 Ogong-ro Deokjin-gu, Jeonju-si Jeollabuk-do 54872 Republic of Korea
value seen: Jeonju
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Addison 5080 Spectrum Drive, Suite #1000E Addison, TX 75001
value seen: Addison
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Greenwich 591 West Putnam Avenue Greenwich, CT 06830
value seen: Greenwich
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Los Angeles 1640 S. Sepulveda Blvd., Suite 460 Los Angeles, CA 90025
value seen: Los Angeles
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### New York 40 10th Ave, 8th Floor New York, NY 10014
value seen: New York
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### San Francisco One Sansome Street, Suite 3200 San Francisco, CA 94104
value seen: San Francisco
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
### Washington, D.C. 1255 23rd Street NW, Suite 250 Washington, D.C. 20037
value seen: Washington, D.C.
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
Unit GD-GB-00-15-BC-30-0 Level 15, Gate Building Dubai, United Arab Emirates
value seen: Dubai
https://www.starwoodcapital.com/contact-us/

Sources: office cities

COMPANYdate not shown in source

Contact Us - Starwood Capital Group

Starwood Capital Group
One Berkeley St London, W1J 8DJ United Kingdom
value seen: London
https://www.starwoodcapital.com/contact-us/

Partners

4 partners
Trinitas Ventures
joint venture

The joint venture combines Starwood's institutional capital and investment expertise with Trinitas' integrated ability to identify, capitalize, develop, construct, and manage purpose-built student housing at three U.S. university sites.

Fontainebleau Development
joint venture

The companies partnered on 1 Homes Jupiter Island, a 26-residence oceanfront development in South Florida, with a controlled Starwood affiliate and Starwood Hotels.

Toll Brothers City Living
joint venture

A joint venture was selected to develop a hotel and residential complex at Pier 1 in Brooklyn Bridge Park, including a 200-room hotel and 159 residential units.

Brooklyn Bridge Park Corporation
government partner

The Brooklyn Bridge Park public-private partnership covered the Pier 1 hotel and residential complex and its long-term ground leases.

Sources: name

PRESS2026-09-09

Starwood Capital Group Announces Joint Venture with Trinitas Ventures

Trinitas Ventures · carried by prnewswire.com
Starwood Capital Group ("Starwood"), a leading global private investment firm, and Trinitas Ventures ("Trinitas"), a fully integrated real estate firm specializing in the investment, development, construction, and management of high-quality residential communities, have formed a joint venture
value seen: Trinitas Ventures
https://www.prnewswire.com/news-releases/starwood-capital-group-announces-joint-venture-with-trinitas-ventures-302873696.html

Sources: partner type

PRESS2026-09-09

Starwood Capital Group Announces Joint Venture with Trinitas Ventures

Trinitas Ventures · carried by prnewswire.com
have formed a joint venture ("the Partnership") to develop purpose-built student housing at three leading universities across the United States.
value seen: joint venture
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.prnewswire.com/news-releases/starwood-capital-group-announces-joint-venture-with-trinitas-ventures-302873696.html

Sources: summary

PRESS2026-09-09

Starwood Capital Group Announces Joint Venture with Trinitas Ventures

Starwood Capital Group · carried by prnewswire.com
The partnership combines Starwood's institutional capital and investment expertise with Trinitas' proven ability to identify, capitalize, develop, construct, and manage institutional-quality student housing communities.
value seen: The partnership combines Starwood's institutional capital and investment expertise with Trinitas' proven ability to identify, capitalize, develop, construct, and manage institutional-quality student housing communities.
https://www.prnewswire.com/news-releases/starwood-capital-group-announces-joint-venture-with-trinitas-ventures-302873696.html

Sources: name

PRESS2025-04-10

STARWOOD CAPITAL GROUP AND FONTAINEBLEAU DEVELOPMENT DEBUT 1 HOMES JUPITER ISLAND, THE PINNACLE OF LUXURY OCEANFRONT LIVING IN SOUTHEAST FLORIDA

Fontainebleau Development · carried by prnewswire.com
Starwood Capital Group ... and Fontainebleau Development ... are raising the bar for South Florida luxury living with the development of 1 Homes Jupiter Island.
value seen: Fontainebleau Development
https://www.prnewswire.com/news-releases/starwood-capital-group-and-fontainebleau-development-debut-1-homes-jupiter-island-the-pinnacle-of-luxury-oceanfront-living-in-southeast-florida-302426103.html

Sources: partner type

PRESS2025-04-10

STARWOOD CAPITAL GROUP AND FONTAINEBLEAU DEVELOPMENT DEBUT 1 HOMES JUPITER ISLAND, THE PINNACLE OF LUXURY OCEANFRONT LIVING IN SOUTHEAST FLORIDA

Fontainebleau Development · carried by prnewswire.com
Created in partnership with a controlled affiliate of Starwood Capital and Starwood Hotels & Resorts
value seen: partnership
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.prnewswire.com/news-releases/starwood-capital-group-and-fontainebleau-development-debut-1-homes-jupiter-island-the-pinnacle-of-luxury-oceanfront-living-in-southeast-florida-302426103.html

Sources: summary

PRESS2025-04-10

STARWOOD CAPITAL GROUP AND FONTAINEBLEAU DEVELOPMENT DEBUT 1 HOMES JUPITER ISLAND, THE PINNACLE OF LUXURY OCEANFRONT LIVING IN SOUTHEAST FLORIDA

Fontainebleau Development · carried by prnewswire.com
1 Homes Jupiter Island consists of 26 oceanfront estate residences
value seen: 26 oceanfront estate residences
value paraphrased from this source
https://www.prnewswire.com/news-releases/starwood-capital-group-and-fontainebleau-development-debut-1-homes-jupiter-island-the-pinnacle-of-luxury-oceanfront-living-in-southeast-florida-302426103.html

Sources: name

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
the board of Brooklyn Bridge Park has voted to designate a joint venture between Toll Brothers City Living and Starwood Capital Group as the developer
value seen: Toll Brothers City Living
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Sources: partner type

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
a joint venture between Toll Brothers City Living and Starwood Capital Group as the developer of an approximately 550,000-square-foot development complex
value seen: joint venture
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Sources: summary

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
to develop hotel and residential complex at Pier 1 in Brooklyn Bridge Park
value seen: hotel and residential complex
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Sources: name

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
Brooklyn Bridge Park Corporation, known as Brooklyn Bridge Park, is the not-for-profit entity responsible for the planning, construction, maintenance and operation of Brooklyn Bridge Park
value seen: Brooklyn Bridge Park Corporation
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Sources: partner type

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
the investment by their development partners will strengthen the public-private partnership
value seen: public-private partnership
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Sources: summary

PRESS2012-06-19

MAYOR BLOOMBERG ANNOUNCES SELECTION OF TOLL BROTHERS|STARWOOD CAPITAL GROUP JOINT VENTURE TO DEVELOP

City of New York · carried by starwoodcapital.com
Brooklyn Bridge Park Corporation, known as Brooklyn Bridge Park, is the not-for-profit entity responsible for the planning, construction, maintenance and operation of Brooklyn Bridge Park
value seen: planning, construction, maintenance and operation of Brooklyn Bridge Park
https://www.starwoodcapital.com/wp-content/uploads/2014/09/42-NYC_Brooklyn_Bridge_Park_Press_Release_FINAL.pdf

Registrations & licences

COMPANY NUMBERM16000009906
Florida Division of Corporations (Sunbiz) · US · ACTIVE
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries
United Statesactive 7 projects tracked

What they build

5 types
Hotel5 of 7
Retail2 of 7
Mixed use2 of 7
Residential, for rent1 of 7
Office1 of 7
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
BS
Barry Sternlicht
Barry Sternlicht formed Starwood Capital Group in 1991 and remains its Chairman & CEO. The company credits him with structuring investments exceeding $280 billion, building Starwood Hotels & Resorts Worldwide, and creating the W Hotels and St. Regis brands.
Current title
Chairman & CEO
since formed in 1991
Experience
35+ years investing
Companies before
Starwood Hotels & Resorts WorldwideStarwood Hotels
Education
Brown UniversityBA, magna cum laude (with honors)
Harvard Business SchoolMBA with distinction
Other boards
The Estée Lauder CompaniesThe Real Estate RoundtableThe Robin Hood FoundationDreamland Film & Performing Arts CenterAmericans for the Arts Executive Advisory Board
Known for
FounderChairman & CEOHotel-brand creator$280B+ structured investmentsMBA
The key is staying disciplined—owning the right sectors in the right markets. ExecEdge 2025-07-07https://executives-edge.com/inside-starwoods-sreit-a-conversation-with-barry-sternlicht/
Our job is to protect long-term value for all investors. ExecEdge 2025-07-07https://executives-edge.com/inside-starwoods-sreit-a-conversation-with-barry-sternlicht/

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Barry Sternlicht received his BA, magna cum laude (with honors), from Brown University. He later earned an MBA with distinction from Harvard Business School.
value seen: BA, magna cum laude (with honors); MBA with distinction
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Barry Sternlicht is Chairman & CEO of Starwood Capital Group, the private alternative investment firm he formed in 1991 that is focused on global real estate.
value seen: Barry Sternlicht
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: other boards

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Sternlicht serves on the Board of Directors of The Estée Lauder Companies and the Real Estate Roundtable. Additionally, he ... is currently a board member of The Robin Hood Foundation, and also serves on the boards of the Dreamland Film & Performing Arts Center, and the Executive Advisory Board of Americans for the Arts.
value seen: The Estée Lauder Companies; The Real Estate Roundtable; The Robin Hood Foundation; Dreamland Film & Performing Arts Center; Americans for the Arts Executive Advisory Board
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: previous companies

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
From 1995 through early 2005, Mr. Sternlicht was Chairman and CEO of Starwood Hotels & Resorts Worldwide, a company he founded in 1995. In 2008, Mr. Sternlicht founded SH Group (now called Starwood Hotels).
value seen: Starwood Hotels & Resorts Worldwide; Starwood Hotels
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: quote

PRESS2025-07-07

Inside Starwood’s SREIT: A Conversation with Barry Sternlicht

ExecEdge · carried by executives-edge.com
The key is staying disciplined—owning the right sectors in the right markets.
value seen: The key is staying disciplined—owning the right sectors in the right markets.
https://executives-edge.com/inside-starwoods-sreit-a-conversation-with-barry-sternlicht/

Sources: quote

PRESS2025-07-07

Inside Starwood’s SREIT: A Conversation with Barry Sternlicht

ExecEdge · carried by executives-edge.com
Our job is to protect long-term value for all investors.
value seen: Our job is to protect long-term value for all investors.
https://executives-edge.com/inside-starwoods-sreit-a-conversation-with-barry-sternlicht/

Sources: since

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
the private alternative investment firm he formed in 1991
value seen: formed in 1991
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: summary

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
For the past 35 years, Mr. Sternlicht has structured investments with an asset value exceeding $280 billion. From 1995 through early 2005, Mr. Sternlicht was Chairman and CEO of Starwood Hotels & Resorts Worldwide, a company he founded in 1995. Mr. Sternlicht created W Hotels ... and built the St. Regis Hotels brand from a single hotel to a global brand.
value seen: Barry Sternlicht formed Starwood Capital Group in 1991 and remains its Chairman & CEO. The company credits him with structuring investments exceeding $280 billion, building Starwood Hotels & Resorts Worldwide, and creating the W Hotels and St. Regis brands.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
For the past 35 years, Mr. Sternlicht has structured investments with an asset value exceeding $280 billion.
value seen: Founder; Chairman & CEO; 35+ years investing; Hotel-brand creator; $280B+ structured investments; MBA
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Barry Sternlicht is Chairman & CEO of Starwood Capital Group
value seen: Chairman & CEO
https://www.starwoodcapital.com/who-we-are/our-team/
JP
Jonathan Pollack
Jonathan Pollack is President of Starwood Capital Group, managing daily operations and guiding firm strategy while overseeing global investment activity, capital markets and investor relations. Before joining Starwood, he led Blackstone’s real-estate-credit business and previously held global commercial-real-estate and capital-markets roles at Deutsche Bank after starting at Nomura Group.
Current title
President
Experience
no career length stated
Companies before
BlackstoneDeutsche BankNomura Group
Education
Northwestern UniversityB.A. in Economics
Other boards
Vice Chairman, Starwood Property TrustBoard of Trustees, East Harlem Tutorial Program
Known for
PresidentExecutive CommitteeInvestment Committeeex-Blackstoneex-Deutsche Bank
since beginning in 2025; current company profile identifies him as President
I have known Jonathan for more than a decade, and he is universally respected across our industry with unparalleled relationships and a track record of success. Starwood Capital Group via PR Newswire 2024-02-26https://www.prnewswire.com/news-releases/starwood-capital-group-appoints-jonathan-pollack-as-president-302071588.html

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Pollack graduated from Northwestern University with a B.A. in Economics.
value seen: B.A. in Economics
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Jonathan Pollack is President of Starwood Capital Group, where he is responsible for managing the daily operations of the business and guiding Firm strategy.
value seen: Jonathan Pollack
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: other boards

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
He is a member of the Board of Trustees of East Harlem Tutorial Program, a leading charter school and after school program in New York City.
value seen: East Harlem Tutorial Program
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: previous companies

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Pollack joined Starwood Capital from Blackstone ... Prior to joining Blackstone in 2015, Mr. Pollack was the Global Head of Commercial Real Estate at Deutsche Bank ... Mr. Pollack joined Deutsche Bank in 1999 from Nomura Group.
value seen: Blackstone; Deutsche Bank; Nomura Group
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: quote

PRESS2024-02-26

Starwood Capital Group Appoints Jonathan Pollack as President

Starwood Capital Group via PR Newswire
I have known Jonathan for more than a decade, and he is universally respected across our industry with unparalleled relationships and a track record of success.
value seen: I have known Jonathan for more than a decade, and he is universally respected across our industry with unparalleled relationships and a track record of success.
https://www.prnewswire.com/news-releases/starwood-capital-group-appoints-jonathan-pollack-as-president-302071588.html

Sources: since

PRESS2024-02-26

Starwood Capital Group Appoints Jonathan Pollack as President

Starwood Capital Group via PR Newswire
today announced that Jonathan Pollack will join the firm beginning in 2025 as its President
value seen: beginning in 2025
https://www.prnewswire.com/news-releases/starwood-capital-group-appoints-jonathan-pollack-as-president-302071588.html

Sources: summary

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Jonathan Pollack is President of Starwood Capital Group, where he is responsible for managing the daily operations of the business and guiding Firm strategy. ... Mr. Pollack joined Starwood Capital from Blackstone ... Prior to joining Blackstone in 2015, Mr. Pollack was the Global Head of Commercial Real Estate at Deutsche Bank ... Mr. Pollack joined Deutsche Bank in 1999 from Nomura Group.
value seen: Jonathan Pollack is President of Starwood Capital Group, managing daily operations and guiding firm strategy while overseeing global investment activity, capital markets and investor relations. Before joining Starwood, he led Blackstone’s real-estate-credit business and previously held global commercial-real-estate and capital-markets roles at Deutsche Bank after starting at Nomura Group.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
As a member of Starwood’s Executive and Investment Committees, Mr. Pollack oversees global investment activity, capital markets, and investor relations. Mr. Pollack joined Starwood Capital from Blackstone ... Mr. Pollack graduated from Northwestern University with a B.A. in Economics.
value seen: President; Executive Committee; Investment Committee; ex-Blackstone; ex-Deutsche Bank; Northwestern economics
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Jonathan Pollack is President of Starwood Capital Group
value seen: President
https://www.starwoodcapital.com/who-we-are/our-team/
AJ
Andrew J. Sossen
Andrew Sossen is Senior Managing Director and COO, working with the CEO and President on day-to-day management, operations and strategy. He oversees capital raising, investor relations, finance, technology, portfolio and risk management, sustainability and human resources; his prior career includes senior legal and operating roles at Starwood Property Trust, KKR and Simpson Thacher.
Current title
Senior Managing Director and Chief Operating Officer
Experience
no career length stated
Companies before
Starwood Property TrustKKR Financial Holdings LLCKKR Asset ManagementSimpson Thacher & Bartlett LLP
Education
University of PennsylvaniaB.A. and J.D.
Other boards
Former trustee, Starwood Waypoint Residential Trust
Known for
COOSenior Managing DirectorExecutive CommitteeInvestment Committeeex-KKR
since rejoin the firm in September 2024
Andrew can hit the ground running. He knows our team, our culture, and our desire to excel in all our endeavors. Starwood Capital Group via PR Newswire 2024-08-13https://www.prnewswire.com/news-releases/starwood-capital-appoints-andrew-sossen-senior-managing-director-chief-operating-officer-302221135.html

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Sossen received both his B.A. and J.D. degrees from the University of Pennsylvania.
value seen: B.A. and J.D.
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Andrew Sossen is a Senior Managing Director and Chief Operating Officer of Starwood Capital Group.
value seen: Andrew J. Sossen
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: other boards

PRESS2024-08-13

Starwood Capital Appoints Andrew Sossen Senior Managing Director, Chief Operating Officer

Starwood Capital Group via PR Newswire
Mr. Sossen previously served as a trustee of Starwood Waypoint Residential Trust
value seen: Starwood Waypoint Residential Trust
https://www.prnewswire.com/news-releases/starwood-capital-appoints-andrew-sossen-senior-managing-director-chief-operating-officer-302221135.html

Sources: previous companies

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Prior to joining Starwood Property Trust in 2010, Mr. Sossen served as the General Counsel of KKR Financial Holdings LLC and KKR Asset Management ... Mr. Sossen’s career began at Simpson Thacher & Bartlett LLP
value seen: Starwood Property Trust; KKR Financial Holdings LLC; KKR Asset Management; Simpson Thacher & Bartlett LLP
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: quote

PRESS2024-08-13

Starwood Capital Appoints Andrew Sossen Senior Managing Director, Chief Operating Officer

Starwood Capital Group via PR Newswire
Andrew can hit the ground running. He knows our team, our culture, and our desire to excel in all our endeavors.
value seen: Andrew can hit the ground running. He knows our team, our culture, and our desire to excel in all our endeavors.
https://www.prnewswire.com/news-releases/starwood-capital-appoints-andrew-sossen-senior-managing-director-chief-operating-officer-302221135.html

Sources: since

PRESS2024-08-13

Starwood Capital Appoints Andrew Sossen Senior Managing Director, Chief Operating Officer

Starwood Capital Group via PR Newswire
today announced that Andrew J. Sossen will rejoin the firm in September as a Senior Managing Director and Chief Operating Officer
value seen: rejoin the firm in September 2024
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.prnewswire.com/news-releases/starwood-capital-appoints-andrew-sossen-senior-managing-director-chief-operating-officer-302221135.html

Sources: summary

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
In this role, Mr. Sossen works in conjunction with the Firm’s Chief Executive Officer and President in the day-to-day management, operations, and strategy of the business. ... he is responsible for overseeing Capital Raising and Investor Relations, Accounting and Finance, Information Technology, Portfolio and Risk Management, Sustainability and Human Resources.
value seen: Andrew Sossen is Senior Managing Director and COO, working with the CEO and President on day-to-day management, operations and strategy. He oversees capital raising, investor relations, finance, technology, portfolio and risk management, sustainability and human resources; his prior career includes senior legal and operating roles at Starwood Property Trust, KKR and Simpson Thacher.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Sossen is a member of the Firm’s Executive and Investment Committees. Prior to joining Starwood Property Trust in 2010, Mr. Sossen served as the General Counsel of KKR Financial Holdings LLC and KKR Asset Management ... Mr. Sossen received both his B.A. and J.D. degrees from the University of Pennsylvania.
value seen: COO; Senior Managing Director; Executive Committee; Investment Committee; ex-KKR; J.D.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Andrew Sossen is a Senior Managing Director and Chief Operating Officer of Starwood Capital Group.
value seen: Senior Managing Director and Chief Operating Officer
https://www.starwoodcapital.com/who-we-are/our-team/
EF
Ellis F. Rinaldi
Ellis Rinaldi is Co-General Counsel and a member of Starwood Capital’s Executive Committee. He has represented the firm’s legal interests since 1991 across acquisitions, financing, asset management and strategic planning, and is the managing member of the firm’s lead outside-counsel practice, Rinaldi, Finkelstein & Franklin.
Current title
Senior Managing Director, Co-General Counsel
Experience
no career length stated
Companies before
Winthrop, Stimson, Putnam & RobertsPircher, Nichols & MeeksRinaldi, Finkelstein & Franklin, L.L.C.
Education
George Washington UniversityJD
University of Massachusetts at AmherstBBA in accounting, summa cum laude
Other boards
none sourced
Known for
Senior Managing DirectorCo-General CounselExecutive CommitteeSince 1991JD
since represented Starwood Capital’s legal interests since 1991; officer since 1999

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Rinaldi received his JD from George Washington University ... and his BBA degree, summa cum laude, in accounting from the University of Massachusetts at Amherst
value seen: JD; BBA degree, summa cum laude, in accounting
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Ellis F. Rinaldi Senior Managing Director, Co-General Counsel
value seen: Ellis F. Rinaldi
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: previous companies

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Rinaldi was an associate at the law firm of Winthrop, Stimson, Putnam & Roberts and then Pircher, Nichols & Meeks, prior to forming Rinaldi, Finkelstein & Franklin, L.L.C.
value seen: Winthrop, Stimson, Putnam & Roberts; Pircher, Nichols & Meeks; Rinaldi, Finkelstein & Franklin, L.L.C.
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: since

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Rinaldi has represented Starwood Capital’s legal interests since 1991 ... Mr. Rinaldi became an officer of Starwood Capital in 1999
value seen: represented Starwood Capital’s legal interests since 1991; officer since 1999
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: summary

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Ellis Rinaldi is Co-General Counsel at Starwood Capital Group. Mr. Rinaldi has represented Starwood Capital’s legal interests since 1991 ... and is a member of Starwood’s Executive Committee.
value seen: Ellis Rinaldi is Co-General Counsel and a member of Starwood Capital’s Executive Committee. He has represented the firm’s legal interests since 1991 across acquisitions, financing, asset management and strategic planning, and is the managing member of the firm’s lead outside-counsel practice, Rinaldi, Finkelstein & Franklin.
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Rinaldi became an officer of Starwood Capital in 1999 and is a member of Starwood’s Executive Committee. Mr. Rinaldi received his JD from George Washington University ... and his BBA degree, summa cum laude, in accounting from the University of Massachusetts at Amherst
value seen: Senior Managing Director; Co-General Counsel; Executive Committee; Since 1991; JD; Accounting BBA
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Senior Managing Director, Co-General Counsel
value seen: Senior Managing Director, Co-General Counsel
https://www.starwoodcapital.com/who-we-are/our-team/
JG
John Gonnella
John Gonnella leads U.S. asset management and oversees strategy, value creation, investment performance and execution across Starwood Capital’s U.S. equity investments. He joined from Centerbridge Partners after senior roles at Northwood Investors and Morgan Stanley Real Estate Funds, bringing a two-decade real-estate investment and asset-management track record.
Current title
Senior Managing Director, Head of Asset Management, U.S.
Experience
no career length stated
Companies before
Centerbridge PartnersNorthwood InvestorsMorgan Stanley Real Estate Funds
Education
Seton Hall University, Stillman School of BusinessBachelor of Science
Other boards
Merit Hill CapitalResort Finance America, LLCSuntex Marina Investors, LLC
Known for
Senior Managing DirectorU.S. asset managementInvestment Committeeex-Centerbridgeex-Northwood
https://linkedin.com/in/john-gonnella-2a639b37
since effective April 20, 2026
The Firm’s track record of innovation and strong investment performance is exceptional, and I am excited to contribute to its continued success across asset classes while helping to create enduring value at both the portfolio and asset level. Starwood Capital Group 2026-02-02https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Gonnella received a Bachelor of Science degree from the Stillman School of Business at Seton Hall University.
value seen: Bachelor of Science degree
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANY2026-02-02

Industry Veteran Brings Significant Value Creation and Asset Management Expertise to Expanding Senior Leadership Team

Starwood Capital Group
Starwood Capital Appoints John Gonnella as Head of U.S. Asset Management, effective April 20, 2026.
value seen: John Gonnella
https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: other boards

COMPANY2026-02-02

Industry Veteran Brings Significant Value Creation and Asset Management Expertise to Expanding Senior Leadership Team

Starwood Capital Group
Mr. Gonnella has served on the boards of multiple large, multi asset real estate and consumer businesses, including Merit Hill Capital, Resort Finance America, LLC, and Suntex Marina Investors, LLC.
value seen: Merit Hill Capital; Resort Finance America, LLC; Suntex Marina Investors, LLC
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: previous companies

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Prior to joining Starwood Capital, Mr. Gonnella served as Senior Managing Director and Head of Real Estate Asset Management at Centerbridge Partners, as well as Vice President at Northwood Investors and Associate with Morgan Stanley Real Estate Funds.
value seen: Centerbridge Partners; Northwood Investors; Morgan Stanley Real Estate Funds
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: quote

COMPANY2026-02-02

Industry Veteran Brings Significant Value Creation and Asset Management Expertise to Expanding Senior Leadership Team

Starwood Capital Group
The Firm’s track record of innovation and strong investment performance is exceptional, and I am excited to contribute to its continued success across asset classes while helping to create enduring value at both the portfolio and asset level.
value seen: The Firm’s track record of innovation and strong investment performance is exceptional, and I am excited to contribute to its continued success across asset classes while helping to create enduring value at both the portfolio and asset level.
https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: since

COMPANY2026-02-02

Industry Veteran Brings Significant Value Creation and Asset Management Expertise to Expanding Senior Leadership Team

Starwood Capital Group
Starwood Capital Appoints John Gonnella as Head of U.S. Asset Management, effective April 20, 2026.
value seen: effective April 20, 2026
https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: summary

COMPANY2026-02-02

Industry Veteran Brings Significant Value Creation and Asset Management Expertise to Expanding Senior Leadership Team

Starwood Capital Group
Mr. Gonnella is a deeply experienced real estate investment and asset management executive with a two-decade track record of driving value creation across complex, multi-billion-dollar portfolios. ... Mr. Gonnella joins Starwood Capital from Centerbridge Partners ... Prior to Centerbridge, he served as Vice President at Northwood Investors ... and ... an associate with Morgan Stanley Real Estate Funds.
value seen: John Gonnella leads U.S. asset management and oversees strategy, value creation, investment performance and execution across Starwood Capital’s U.S. equity investments. He joined from Centerbridge Partners after senior roles at Northwood Investors and Morgan Stanley Real Estate Funds, bringing a two-decade real-estate investment and asset-management track record.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/wp-content/uploads/2026/02/Starwood-Press-Release-Gonnella.pdf

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
He is also a member of Starwood’s Investment Committee. Prior to joining Starwood Capital, Mr. Gonnella served as Senior Managing Director ... at Centerbridge Partners, as well as Vice President at Northwood Investors ... Mr. Gonnella received a Bachelor of Science degree from ... Seton Hall University.
value seen: Senior Managing Director; U.S. asset management; Investment Committee; ex-Centerbridge; ex-Northwood; Seton Hall BS
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
John Gonnella is a Senior Managing Director and Head of Asset Management, U.S. at Starwood Capital Group.
value seen: Senior Managing Director, Head of Asset Management, U.S.
held out of the figures · the quote does not carry this value
https://www.starwoodcapital.com/who-we-are/our-team/
ML
Michael Lefton
Michael Lefton is Starwood Capital’s Senior Managing Director and Global Head of Capital Raising and Investor Relations. His remit places him among the firm’s senior leaders responsible for raising capital and managing institutional and high-net-worth investor relationships; the company profile records a Wharton economics degree.
Current title
Senior Managing Director, Global Head of Capital Raising and Investor Relations
Experience
no career length stated
Companies before
none sourced
Education
Wharton School at the University of PennsylvaniaBS in economics
Other boards
none sourced
Known for
Senior Managing DirectorGlobal capital raisingInvestor relationsWharton economics
https://www.linkedin.com/in/michael-lefton-b25b464

Sources: education

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Mr. Lefton received a BS in economics from the Wharton School at the University of Pennsylvania.
value seen: BS in economics
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: full name

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Michael Lefton
value seen: Michael Lefton
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: summary

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Senior Managing Director, Global Head of Capital Raising and Investor Relations ... Mr. Lefton received a BS in economics from the Wharton School at the University of Pennsylvania.
value seen: Michael Lefton is Starwood Capital’s Senior Managing Director and Global Head of Capital Raising and Investor Relations. His remit places him among the firm’s senior leaders responsible for raising capital and managing institutional and high-net-worth investor relationships; the company profile records a Wharton economics degree.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: tags

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Senior Managing Director, Global Head of Capital Raising and Investor Relations
value seen: Senior Managing Director; Global capital raising; Investor relations; Wharton economics
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.starwoodcapital.com/who-we-are/our-team/

Sources: title

COMPANYdate not shown in source

Our Team - Starwood Capital Group

Starwood Capital Group
Senior Managing Director, Global Head of Capital Raising and Investor Relations
value seen: Senior Managing Director, Global Head of Capital Raising and Investor Relations
https://www.starwoodcapital.com/who-we-are/our-team/

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 1 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

4 evidenced cases

Subsequently completed; historical exception · Last checked: 2026-10-14

Original delivery commitment: Nov 2021. Source publication dates and resolution history are shown with the evidence below.

OVERDUE · Resolved historical case · Several lawsuits from contractors pushed the resort’s opening date.

Evidence for delay_causes
2023-02-10
thegardenisland.com
logistical issues and several lawsuits from contractors pushed the resort’s opening date
value seen: CONTRACTOR_FAILURE
value paraphrased from this source
https://www.thegardenisland.com/2023/02/10/business/1-hotel-hanalei-bay-set-to-open-wednesday/

Subsequently completed; historical exception · Last checked: 2026-10-14

Original delivery commitment: Q3 2021. Source publication dates and resolution history are shown with the evidence below.

OVERDUE · The project opened about a year after the original targeted completion date; the owner alleged contractor delays and defective work.

Evidence for delay_causes
2022-09-26
nashvillepost.com
The 30-story Embassy Suites portion of the project opened in June, with the 18-story 1 Hotel following in July. That was about a year after the original targeted completion date
value seen: CONTRACTOR_FAILURE
value paraphrased from this source
https://www.nashvillepost.com/business/development/sobro-hotel-developer-claims-contractor-delays-defects-have-cost-millions/article_6e32ea80-3dd1-11ed-a7c4-2f90edc69fee.html

Subsequently completed; historical exception · Last checked: 2026-10-14

Original delivery commitment: Q4 2021. Source publication dates and resolution history are shown with the evidence below.

OVERDUE · June 2022 · The project opened about a year after its original targeted completion date; the owner alleged contractor delays and defective work.

Evidence for delay_causes
2022-12-26
nashvillepost.com
The 30-story Embassy Suites portion of the project opened in June, with the 18-story 1 Hotel following in July. That was about a year after the original targeted completion date
value seen: CONTRACTOR_FAILURE
value paraphrased from this source
https://www.nashvillepost.com/business/development/sobro-hotel-developer-claims-contractor-delays-defects-have-cost-millions/article_6e32ea80-3dd1-11ed-a7c4-2f90edc69fee.html

Subsequently completed; historical exception · Last checked: 2026-10-14

Original delivery commitment: Q3 2015. Source publication dates and resolution history are shown with the evidence below.

OVERDUE · 2012 · Resolved historical case · Hurricane Sandy caused damage and destruction, waterfront zoning changes, code changes, and a massive redesign effort.

Evidence for delay_causes
2017-12-16
prnewswire.com
when Hurricane Sandy hit the East Coast in 2012... Due to the damage and destruction, the team was informed the waterfront zoning had changed... which triggered a massive redesign effort
value seen: FORCE_MAJEURE
value paraphrased from this source
https://www.prnewswire.com/news-releases/1-hotel-brooklyn-bridge-opens-sprouting-a-new-generation-of-nature-led-luxury-hotels-300408419.html

Completed projects

7 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
LumaireWest Palm Beach, United States
Downtown West Palm Beach
residential for rent, retail, mixed use457123—USD 96.4m
construction loan
—2024Aug. 12Jan 2024 – Apr 2024Aug 2024+5.5 mo
(+4.0 to +7.0)
estimatedcompleted
1 Hotel Hanalei BayUnited States
Princeville
hotel2521—290,000 sq ftUSD 300m
other
—2018Nov. 16, 2018Nov 2021Feb 2023+15.0 mo
(+15.0 to +15.0)
sourcedcompleted
1 Hotel NashvilleNashville, United States
SoBro
hotel215118———2019April 2, 2019Sep 2021 – Dec 2021Jul 2022+8.5 mo
(+7.0 to +10.0)
sourcedcompleted
Embassy Suites by Hilton Nashville DowntownNashville, United States
SoBro
hotel506130———2019April 2, 2019Oct 2021 – Dec 2021Jun 2022+7.0 mo
(+6.0 to +8.0)
sourcedcompleted
2340 Collins AvenueMiami Beach, United States
Collins Park
office, retail, mixed use—6144,430 sq ftUSD 76.2m
construction loan
—2019September 23, 2019Jan 2021 – Dec 2021Dec 2021+5.5 mo
(0.0 to +11.0)
sourcedcompleted
1 Hotel West HollywoodWest Hollywood, United States
West Hollywood
hotel2851————2017July 27, 2017Jan 2018 – Dec 2018Jul 2019+12.5 mo
(+7.0 to +18.0)
sourcedcompleted
1 Hotel Brooklyn BridgeBrooklyn, United States
DUMBO
hotel194110———2012June 19, 2012Sep 2015 – Nov 2015Feb 2017+16.0 mo
(+15.0 to +17.0)
sourcedcompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

7 found
COMPANY AWARD Winner 2021 (reported by PERE on March 1, 2022)
PERE Firm of the Year
Starwood Capital won PERE’s Firm of the Year recognition in 2021; the developer reports the award on its accolades page, while PERE’s 2021 winners announcement was published on March 1, 2022.
COMPANY AWARD Winner 2022 (reported March 1, 2023)
PERE Debt Firm of the Year — Europe
Starwood Capital was recognized as Europe’s Debt Firm of the Year in the PERE 2022 awards; a contemporaneous industry account lists Starwood Capital as the winner.
PROJECT AWARD Winner 2022 (reported October 5, 2022)
Structures Award: Best Architecture/Design · Starwood Capital Miami Beach Headquarters
The Starwood Capital headquarters in Miami Beach received the South Florida Business Journal’s 2022 Structures Award for Best Architecture/Design.
RANKING Ranked May 24, 2024 (ranking as of January 1, 2024)
Top 50 Affordable Housing Owners of 2023
Starwood Capital Group ranked No. 2 among the listed affordable-housing owners, with 47,339 affordable units and 245 projects as of January 1, 2024.
SUSTAINABILITY Certified 2022 (certification reported in September 2024)
LEED Core & Shell Gold certification · Starwood Capital Group Global Headquarters, Miami Beach
The headquarters achieved LEED Core & Shell certification at the Gold level, according to Starwood Capital Group’s 2024 Responsible Investment Report.
SUSTAINABILITY Certified Mid-October 2023 (reported September 2024)
BREEAM Excellent certification · Starwood Spanish Industrial Portfolio near Madrid
Three industrial assets near Madrid achieved BREEAM Excellent certification in mid-October 2023 after improvements and evidence submission, according to Starwood Capital Group’s Responsible Investment Report.
COMPANY AWARD Winner 2022
PERE Hotels & Leisure Investor of the Year
Starwood Capital was listed as PERE Hotels & Leisure Investor of the Year for 2022; the developer reports the recognition on its accolades page.

Risks

Risk flags

11 found
FINANCIAL DISTRESS January 28, 2026
On January 28, 2026, reporting said Deutsche Bank seized three Oakland office towers previously owned by Starwood Capital through a deed-in-lieu of foreclosure after a default; the unpaid debt was reported at $442.1 million against an original $364.5 million loan.
FINANCIAL DISTRESS May 6, 2026 (reporting); January 2026 (special servicing transfer)
On May 6, 2026, reporting said a Starwood affiliate's $265 million loan secured by a 22-property hotel portfolio had been transferred to special servicing in January for an “imminent monetary default”; the report said Starwood had proposed a modification and that the loan had not yet matured.
FINANCIAL DISTRESS July 5, 2024 (reporting); February 2024 (reported default); June 2024 (foreclosure sale)
On July 5, 2024, reporting said MetLife completed a non-judicial foreclosure on Starwood Capital's and Artisan Ventures' El Segundo office building after the firms defaulted in February on a roughly $85 million loan; the redevelopment plans for an adjacent parking lot reportedly never came to fruition.
DELIVERY DELAY September 2, 2022 (reporting); February 2022 (original completion target); August 1, 2022 (contract termination effective date)
A September 2, 2022 report said Starwood-linked owners' 1 Hotel Hanalei Bay project, originally expected to be completed in February 2022, remained unfinished and was delayed to early 2023 amid a contractor lawsuit and subcontractor lien alleging nonpayment and unsafe working conditions; Starwood's representative called the contractor's claims “completely without merit” and said the owner intended to defend and counterclaim.
FINANCIAL DISTRESS August 19, 2022 (judgment); March 17, 2011 (Chapter 11 filing); 2012 (liquidation)
A judgment published on August 19, 2022 records that Starwood's Anguilla affiliate acquired the project loan after Barnes Bay Development defaulted; the project entered Chapter 11 in March 2011 after construction costs reportedly rose from about $144 million to $327 million, the company became overleveraged and unable to service debt, and was placed in liquidation in 2012.
PROJECT CANCELLED 2026-08-28 publication; appeal withdrawn in July 2026
Starwood Digital Ventures’ Project Washington data-center campus in Delaware cannot proceed under its current design after state regulators ruled it prohibited under the Coastal Zone Act and the developer withdrew its court appeal; Starwood said it was still seeking a possible path forward, so this is not a finding that all future versions are cancelled.
PROJECT CANCELLED 2025-09-17 withdrawal; 2025-09-26 publication
The Starwood-affiliated Nomade Lido/Jaws Estates Capital team withdrew its application to expand Miami Beach’s Standard Hotel and add condominiums after local opposition, while representatives said they planned to resubmit rather than abandon the concept entirely.
PROJECT CANCELLED 2021-12-01
Starwood Capital Group withdrew its permit application for the proposed Princeville Makai Woods 50-tent glamping development in Kauai; the company said it was returning to the drawing board and would review options after the land-use covenant expired in 2026.
PROJECT CANCELLED 2020-12-04
Starwood Retail Partners LLC’s proposed Mall at Wellington Green redevelopment was administratively withdrawn for inactivity after the owner’s plan for housing, a hotel and other uses was derailed by COVID-19; its project agent said Starwood might return with a similar plan, but no completion is documented in the source.
DELIVERY DELAY 2020-08-23; original completion target 2017
The Starwood-backed AS Roma/Tor di Valle stadium and mixed-use development in Rome was still unbuilt in 2020 despite an originally stated 2017 completion target; reporting attributed the delay to planning disputes and a corruption investigation involving local politicians, not Starwood or club officials, and noted Starwood had sold its Roma stake.
DELIVERY DELAY 2024-07-05
A Starwood Capital–Artisan Ventures joint venture’s planned 94,000-square-foot office expansion and parking structure at 1960 East Grand Avenue in El Segundo had not come to fruition by July 2024, when the existing property was foreclosed after the owners defaulted; the source supports an SPV/JV-level event, not broader parent liability.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 14, 2026 this month
Profile last researchedOctober 14, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.